Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
INSTRUCTIONS FOR COMPLETING FORM A AND B Form A and Form B should be completed for Contracts for consulting services in accordance with Section XI.18.C of the Office of the State Comptroller’s Guide to Financial Operations (xxxx://xxx.xxx.xxxxx.xx.xx/agencies/guide/MyWebHelp/), “Consultant Disclosure Legislation,” and the following:
Ordering Guidelines and Processes 1.14.1 For information regarding Ordering Guidelines and Processes for various Network Elements, Combinations and Other Services, TWTC should refer to the “Guides” section of the AT&T Interconnection Web site. TWTC will be notified of any material changes to such “Guides”.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Sentencing Guidelines Calculations 8. Defendant understands that in imposing sentence the Court will be guided by the United States Sentencing Guidelines. Defendant understands that the Sentencing Guidelines are advisory, not mandatory, but that the Court must consider the Guidelines in determining a reasonable sentence.
Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
Flexible Work Schedule A flexible work schedule is any schedule that is not a regular, alternate, 9/80, or 4/10 work schedule and where the employee is not scheduled to work more than 40 hours in the "workweek" as defined in Subsections F. and H., below.
PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.
Schedule for Completing Agreement Closeout Activities Provide All Draft and Final Written Products on a CD-ROM or USB memory stick, organized by the tasks in the Agreement. Products: • Final Meeting Agreement Summary (if applicable) • Schedule for Completing Agreement Closeout Activities • All Draft and Final Written Products
Marketing Plan The MCP shall submit an annual marketing plan to ODM that includes all planned activities for promoting membership in or increasing awareness of the MCP. The marketing plan submission shall include an attestation by the MCP that the plan is accurate is not intended to mislead, confuse or defraud the eligible individuals or ODM.