Supply of Outside Resources/Applicable Terms of Delivery Sample Clauses

Supply of Outside Resources/Applicable Terms of Delivery. ABG permits ATBB to use the facilities of ABG listed below: a) internal plant road network and access to the rail network b) weighing facilities at the entries to the plant c) electric power network d) pipes e) sewer lines and canals f) telecommunications In connection with its existing third-party supply agreements, ABG supplies ATBB with the amounts of electricity, natural gas and drinking water required by ATBB. To that extent, the terms of delivery agreed between ABG and the suppliers of these media and the normal delivery restrictions also apply to ATBB. ATBB may inspect the specific terms of delivery and the delivery restrictions. If ATBB no longer wants to be supplied by ABG with electricity, natural gas or drinking water, or if ABG is not, or will in the future no longer be, authorized to supply electricity, natural gas and drinking water to ATBB, ABG allows ATBB to procure its own supply of the respective media. ATBB indemnifies ABG against all costs incurred as a result of the construction and operation of corresponding supply facilities.
Sample 1
AutoNDA by SimpleDocs

Related to Supply of Outside Resources/Applicable Terms of Delivery

  • Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Terms of Delivery The Terms of Delivery are contained in the General Conditions of Contract (GCC) and Special Conditions of Contract.

  • Optional Xactimate Response Attachment (Part 2)

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

  • Enterprise Information Management Standards Grantee shall conform to HHS standards for data management as described by the policies of the HHS Office of Data, Analytics, and Performance. These include, but are not limited to, standards for documentation and communication of data models, metadata, and other data definition methods that are required by HHS for ongoing data governance, strategic portfolio analysis, interoperability planning, and valuation of HHS System data assets.

  • Long Description (If Applicable Training to provide the knowledge, skills and abilities needed as a result of agency mission, policies, or procedures. . Training to acquire the knowledge, skills and abilities needed as a result of assignment to new duties and responsibilities when such training is not part of a planned, career development program (e.g., training provided to a staffing specialist who has been newly assigned to a position involving classification duties).

  • Description of Goods or Services and Additional Terms and Conditions The Contractor shall perform as set forth in Exhibit A. For purposes of this Contract, to perform and the performance in Exhibit A is referred to as “Perform” and the “Performance.”

  • OTHER APPLICABLE TERMS & CONDITIONS 5.1. All registered E-bidders at PAH website shall undertake to fully comply with the Terms and Conditions herein. In addition all successful E-Bidders shall also be bound by the terms and conditions as stipulated in the Proclamation of Sale. 5.2. The Auctioneer may from time to time vary, modify or delete any terms and conditions herein without having to give prior notice to the registered E-bidders. 5.3. E-bidders are responsible to ensure that their internet access is in good condition during the whole process of public auction until conclusion thereof. Unsatisfactory internet access may disrupt the bidding made by the E-Bidders. 5.4. The Auctioneer or the PAH Website shall not be held liable for any disruptions delays, failures, errors, omissions or loss of information due to the unsatisfactory internet access or any online interruption that may howsoever occur during the process of the online public auction at PAH Website. 5.5. PAH Website is owned and operated by PROPERTY AUCTION HOUSE SDN BHD (PAH). The E-bidders agree and accept that PAH or the Assignee Bank in which PAH acts for or their solicitors or any of their respective servants or agents shall not be in any way liable for any claims or loss arising out of the use of the PAH Website.

  • Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!