SUSPENSION OF THE WORK 1. The State, at any time, may suspend all or any part of the services of the Engineer. In such event, the Engineer shall be given notice of such suspension in writing by registered or certified mail to the Engineer's address as furnished to the State for purposes of receiving notices under this contract, by email to the Engineer’s email address as furnished to the State for the purpose of notices, by facsimile transmission telecopy (fax) to the Engineer’s fax number as furnished to the State for the purpose of notices, or by hand delivery.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
Suspension of Works 24.1 Where the Contract is subject to the Construction Contracts Act 2002, the Client hereby expressly acknowledges that:
Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.
– SUSPENSION OF THE CONTRACT Without prejudice to the Agency's right to terminate the Contract, the Agency may at any time and for any reason suspend execution of the tasks under the Contract or any part thereof. Suspension shall take effect on the day the Contractor receives notification by registered letter with acknowledgment of receipt or equivalent, or at a later date where the notification so provides. The Agency may at any time following suspension give notice to the Contractor to resume the work suspended. The Contractor shall not be entitled to claim compensation on account of suspension of the Contract or of part thereof.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds. Contractor further certifies under pains and penalties of perjury that, as of the date this contract amendment is signed, Contractor is not presently debarred, suspended, nor named on the State’s debarment list at: xxxx://xxx.xxxxxxx.xxx/purchasing-contracting/debarment This document consists of 2 pages. Except as modified by this Amendment No. 2, all provisions of the Contract remain in full force and effect. The signatures of the undersigned indicate that each has read and agrees to be bound by this Amendment to the Contract. STATE OF VERMONT XXXXXX AIR SYSTEMS, INC. By: By: Name: Name: Title: Title: Date: Date: Contract #37375 Amendment #1 STATE OF VERMONT CONTRACT AMENDMENT It is hereby agreed by and between the State of Vermont, Department of Buildings & General Services (the "State") and Xxxxxx Air Systems, Inc. with a principal place of business in S. Burlington, VT (the "Contractor") that the contract between them originally dated as of November 1, 2018, Contract #37375, as amended to date, (the “Contract”) is hereby amended as follows:
Equipment and Software Requirements In order to view and retain electronic communications that we make available to you, you must have: • A PC or other device with an Internet browser that has “cookies” enabled and supports 128 bit encryption • An Internet connection • An email address • A PDF viewer (such as Adobe Reader) • A printer or computer with sufficient electronic storage space All communications shall be delivered to the last address we have on file for you. These notices will be sent through electronic delivery (email) and will be considered delivered the same day as sent. If you have opted out of electronic delivery, communications sent to you through the United States Postal Service are considered delivered 5 business days after the postmark date. It is your responsibility to notify the Custodian of any email address change or residential address change. We will not be held liable for any losses or damages if you have not provided Custodian with the most current address information. The electronically signed copy of this document should be considered equivalent to a printed hard copy form. It is considered a true and complete record of the document, admissible in arbitration and/or administrative hearings or proceedings. Your electronic signature on the Application and other electronic forms such as the Investment Direction are considered valid and the same as if the paper form or Application were signed.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
Suspension of Access Ricoh reserves the right to suspend or terminate authorizations, or to suspend or block access to all or any part of the Site or Services as provided in paragraph 10 hereof.
