Suspension or Delay of Implementation Activities Sample Clauses

Suspension or Delay of Implementation Activities. Subject to Section 8.12, AT&T reserves the right, in its discretion (acting reasonably) and upon notice to Synacor, to delay or modify the performance of the Implementation Services or any portion of the Implementation Services.
Sample 1
AutoNDA by SimpleDocs
Suspension or Delay of Implementation Activities. VITA shall have the right, in its sole discretion, to suspend or delay the performance of the Implementation Services and/or the transition of all or any part of the Services. If VITA’s decision to suspend or delay is based, in material part, on reasonable concern about Supplier’s ability to perform or Supplier’s failure to perform, VITA shall give notice of the reason for the suspension or delay and an opportunity to resolve the concern or failure and the suspension or delay shall not exceed 90 days. If the concern or failure is not resolved, VITA may extend the suspension or delay. If VITA’s decision to suspend or delay is based, in material part, on reasonable concern about Supplier’s ability to perform or Supplier’s failure to perform, VITA shall not incur any Charges nor shall VITA be required to reimburse expenses in connection with the suspension or delay. If VITA’s decision is not based, in material part, on reasonable concern about Supplier’s ability to perform or Supplier’s failure to perform, VITA shall reimburse Supplier for any additional expenses reasonably incurred by Supplier as a result of such decision, provided that Supplier notifies VITA in advance of such expenses, obtains VITA’s approval prior to incurring such expenses, and uses commercially reasonable efforts to minimize such expenses.
Sample 1
Suspension or Delay of Implementation Activities 
Sample 1

Related to Suspension or Delay of Implementation Activities

  • Suspension of Access Ricoh reserves the right to suspend or terminate authorizations, or to suspend or block access to all or any part of the Site or Services as provided in paragraph 10 hereof.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.

  • Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds.

  • Construction Activities Please list all major construction activities, both planned and completed, to be performed by Seller or the EPC Contractor. Activity EPC Contractor / Subcontractor Completion Date __/__/____ (expected / actual) __/__/____ (expected / actual)

  • Project Implementation The Borrower shall:

  • Suspension of Work Authorization DocuSign Envelope ID: F977C999-9391-4B1E-8882-3E74EBE07795

  • Suspension or Debarment In addition to the representations and requirements set forth in Section C.4: (a) The Contractor certifies for itself and Contractor Parties involved in the administration of federal or state funds that they: (1) are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded by any governmental agency (federal, state or local); (2) within a three year period preceding the effective date of this Contract, have not been convicted or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain or performing a public (federal, state or local) transaction or contract under a public transaction; for violation of federal or state antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements or receiving stolen property; (3) are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (federal, state or local) with commission of any of the above offenses; and (4) have not within a three year period preceding the effective date of this Contract had one or more public transactions terminated for cause or fault. (b) Any change in the above status shall be immediately reported to the Agency.

  • Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.

  • Suspension of Agreement SCEA may suspend this Agreement, entirely or with respect to a particular Licensed Product or program, for a set period of time which shall be specified in writing to Publisher upon the occurrence of any breach of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!