Taking of the Center Sample Clauses

Taking of the Center. If, as a result of any Taking directly affecting portions of the Center or affecting any means of ingress or egress or other means of access to or within the Center, either (i) the conduct of Tenant’s business in the Premises becomes impracticable in Tenant’s reasonable judgment, or (ii) the number of parking spaces within the Parking Area as a whole is reduced below the number of Minimum Free Parking Spaces or the number of parking spaces within the Priority Parking Area is reduced below the applicable number of Premises Minimum Free Parking Spaces specified in Section 1.1, or (iii) ten percent (10%) or more of the Center (by Floor Area) is taken; then in any such event Tenant shall have the right and option to terminate this Lease upon notice to Landlord within thirty (30) days after Tenant is informed of the applicable occurrence. If any Rent or other charge has been paid in advance, Landlord shall refund to Tenant all sums so paid for the period after possession is taken by the condemning authority. Notwithstanding the foregoing, Landlord shall have the right to terminate this Lease in accordance with clause (ii) or (iii) of this Section 17.2 after the first fifteen (15) Lease Years, unless Tenant waives a violation of clause (ii) of this Section 17.2.
Sample 1
AutoNDA by SimpleDocs

Related to Taking of the Center

  • Felling of trees The Authority shall assist the Contractor in obtaining the Applicable Permits for felling of trees in non-forest area to be identified by the Authority for this purpose if, and only if, such trees cause a Material Adverse Effect on the construction or maintenance of the Project Highway. The Contractor shall fell these trees as per the Permits obtained. The cost of such felling shall be borne by the Authority and in the event of any delay in felling thereof for reasons beyond the control of the Contractor; it shall be excused for failure to perform any of its obligations hereunder if such failure is a direct consequence of delay in the felling of trees. The Parties hereto agree that the felled trees shall be deemed to be owned by the Authority and shall be disposed in such manner and subject to such conditions as the Authority may in its sole discretion deem appropriate. For the avoidance of doubt, the Parties agree that if any felling of trees hereunder is in a forest area, the Applicable Permit thereof shall be procured by the Authority within the time specified in the Agreement.

  • Outside Activities of the Limited Partners Subject to the provisions of Section 7.5, which shall continue to be applicable to the Persons referred to therein, regardless of whether such Persons shall also be Limited Partners, any Limited Partner shall be entitled to and may have business interests and engage in business activities in addition to those relating to the Partnership, including business interests and activities in direct competition with the Partnership Group. Neither the Partnership nor any of the other Partners shall have any rights by virtue of this Agreement in any business ventures of any Limited Partner.

  • POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.

  • Outside Activities of Limited Partners Subject to any agreements entered into by a Limited Partner or its Affiliates with the General Partner, Partnership or a Subsidiary, any Limited Partner and any officer, director, employee, agent, trustee, Affiliate or stockholder of any Limited Partner shall be entitled to and may have business interests and engage in business activities in addition to those relating to the Partnership, including business interests and activities in direct competition with the Partnership or that are enhanced by the activities of the Partnership. Neither the Partnership nor any Partners shall have any rights by virtue of this Agreement in any business ventures of any Limited Partner or Assignee. Subject to such agreements, none of the Limited Partners nor any other Person shall have any rights by virtue of this Agreement or the partnership relationship established hereby in any business ventures of any other Person, other than the Limited Partners benefiting from the business conducted by the General Partner, and such Person shall have no obligation pursuant to this Agreement to offer any interest in any such business ventures to the Partnership, any Limited Partner or any such other Person, even if such opportunity is of a character which, if presented to the Partnership, any Limited Partner or such other Person, could be taken by such Person.

  • POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

  • Fitness Center Subject to the provisions of this Section, so long as Tenant is not in Default under this Lease, and provided Tenant’s employees execute a standard waiver of liability form used at the Fitness Center (hereinafter defined) and pay the applicable one time or monthly fee, then Tenant’s employees (the “Fitness Center Users”) shall be entitled to use the KINETIC fitness center (the “Fitness Center”) in the building located at 600 Xxxxxxx Xxxxxx Xxxxx, Xxxxxxx Xxxxx, Xxxxxxxxxx. The use of the Fitness Center shall be subject to the rules and regulations (including rules regarding hours of use) established from time to time by the Fitness Center operator. Landlord and Tenant acknowledge that the use of the Fitness Center by the Fitness Center Users shall be at their own risk. Tenant acknowledges that the provisions of this Section shall not be deemed to be a representation by Landlord that the Fitness Center (or any other fitness facility) shall be continuously operated and maintained throughout the Term of this Lease, and no termination of Tenant’s or the Fitness Center Users’ rights to the Fitness Center shall entitle Tenant to an abatement or reduction in Basic Rent, constitute a constructive eviction, or result in an event of default by Landlord under this Lease. Tenant hereby voluntarily releases, discharges, waives and relinquishes any and all actions or causes of action for personal injury or property damage occurring to Tenant or its employees or agents arising as a result of the use of the Fitness Center, or any activities incidental thereto, wherever or however the same may occur, and further agrees that Tenant will not prosecute any claim for personal injury or property damage against Landlord or any of its officers, agents, servants or employees for any said causes of action. It is the intention of Tenant with respect to the Fitness Center to exempt and relieve Landlord from liability for personal injury or property damage caused by negligence. Tenant’s rights hereunder to permit its employees to use the Fitness Center shall belong solely to Tenant and may not be transferred or assigned without Landlord’s prior written consent, which may be withheld by Landlord in Landlord’s sole discretion.

  • Special Situations XXXXXXX BENEFICIARY agrees to inform AGENCY within one (1) business day of any circumstances or events which may reasonably be considered to jeopardize its capability to continue to meet its obligations under the terms of this Agreement. Incidents may include, but are not limited to, those resulting in injury, media coverage or public reaction that may have an impact on the AGENCY’S or GRANTEE BENEFICIARY’S ability to protect and serve its participants, or other significant effect on the AGENCY or GRANTEE BENEFICIARY. Incidents shall be reported to the designated AGENCY contact below by phone or email only. Incident report information shall not include any identifying information of the participant.

  • Emergency Situations If the condition is an emergency, this will be communicated to the Contractor with the request that corrections are to be accomplished immediately. The Contractor shall respond to the notice in emergency situations within twenty-four hours. If the Contractor fails to respond within this time limit, the Owner may correct the defect and charge the Contractor for the Work. If it is determined the complaint is not the responsibility of the Contractor, the Contractor shall be promptly paid for the cost of the corrective work. The Contractor shall give notice in writing to the Owner when corrections have been completed.

  • Authority of the Asset Manager (a) Except as set forth in Section 2(e) below and in any guidance as may be established from time to time by the managing member of the Series or the Advisory Board, the Asset Manager shall have sole authority and complete discretion over the care, custody, maintenance and management of the Series #TICKER Asset and to take any action that it deems necessary or desirable in connection therewith. The Asset Manager is authorized on behalf of the Series to, among other things: (i) purchase and maintain insurance coverage for the Series #TICKER Asset for the benefit of the Series; (ii) engage third party independent contractors for the care, custody, maintenance and management of the #TICKER Asset; (iii) develop standards for the care and transportation of the Series #TICKER Asset while in and outside of storage, as applicable; (iv) reasonably make all determinations regarding the calculation of fees, expenses and other amounts relating to the Series #TICKER Asset paid by the Asset Manager hereunder; (v) deliver invoices to the managing member of the Company for the payment of all fees and expenses incurred by the Series in connection with the maintenance and operation of the Series #TICKER Asset and ensure delivery of payments to third parties for any such services; and (vi) generally perform any other act necessary to carry out its obligations under this Agreement. (b) The Asset Manager shall have full responsibility for the maintenance of the Series #TICKER Asset and handling of inspections. (c) The Asset Manager shall devote such time to its duties under this Agreement as may be deemed reasonably necessary by the Asset Manager in light of the understanding that such duties are expected to be performed only at occasional or irregular intervals. (d) The Asset Manager may delegate all or any of its duties under this Agreement to any Person who shall perform such delegated duties under the supervision of the Asset Manager on such terms as the Asset Manager shall determine. (e) Notwithstanding any other provision of this Agreement to the contrary, the Asset Manager shall not have the authority to: (i) acquire any asset or service for an amount equal to or greater than 1% of the value of the Series #TICKER Asset as of such date, individually, or 3% of the value of the Series #TICKER Asset as of such date, in the aggregate, without the prior consent of the managing member of the Series; or (ii) sell, transfer or convey the Series #TICKER Asset, provided, however, that the Asset Manager may deliver to the managing member of the Company any offers received by the Asset Manager to purchase the Series #TICKER Asset and any research or analysis prepared by the Asset Manager regarding the potential sale of the Series #TICKER Asset, including market analysis, survey results or information regarding any inquiries received and information regarding potential purchasers.

  • Summer Session A. All ASEs employed in the Summer Session shall receive the same general range adjustment as ASEs received in the preceding Fall term. B. The following articles apply to ASEs who are employed in the summer session: Recognition, Wages (range adjustment only), DCP, Travel, Health and Safety, Leaves, Holidays, Duration, Workspace and Instructional Support, Parking, Grievance and Arbitration, Waiver, Management and Academic Rights, No Strikes, Non-Discrimination, Union Access and Rights, Union Security, Discipline and Dismissal, Emergency Layoff, Employment Files and Evaluations, Definitions, Severability, Labor-Management Meetings, and Classifications. C. The remainder of the articles in the agreement does not apply to ASEs who are employed in the summer session. D. The topic of Summer Session, and effects of changes on terms and conditions of employment for ASEs employed in Summer Session, shall be reopened for bargaining commencing no later than January 2, 2001.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!