Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Additional Requirements for All Policies All policies shall be endorsed to provide at least thirty (30) days' advance written notice to City of cancellation of policy for any reason, nonrenewal or reduction in coverage and specific notice mailed to City's address for notices pursuant to Article 15.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
County Review and Approval of Insurance Requirements The County reserves the right to review and adjust the Required Insurance provisions, conditioned upon County’s determination of changes in risk exposures.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Requirements for All Policies Each policy of insurance required under this Section 11.1 shall: (i) be in a form, and written by an insurer, reasonably acceptable to Landlord, (ii) be maintained at Tenant’s sole cost and expense, and (iii) require at least thirty (30) days’ written notice to Landlord prior to any cancellation, nonrenewal or modification of insurance coverage. Insurance companies issuing such policies shall have rating classifications of “A” or better and financial size category ratings of “VII” or better according to the latest edition of the A.M.
Report Requirements The Company will send to the Reinsurer the following reports electronically, by the times indicated below:
Policy Compliance Violations The Requester and Approved Users acknowledge that the NIH may terminate the DAR, including this Agreement and immediately revoke or suspend access to all controlled-access datasets subject to the NIH GDS Policy at any time if the Requester is found to be no longer in agreement with the principles outlined in the NIH GDS Policy, the terms described in this Agreement, or the Genomic Data User Code of Conduct. The Requester and PI agree to notify the NIH of any violations of the NIH GDS Policy, this Agreement, or the Genomic Data User Code of Conduct data within 24 hours of when the incident is identified. Repeated violations or unresponsiveness to NIH requests may result in further compliance measures affecting the Requester. The Requester and PI agree to notify the appropriate DAC(s) of any unauthorized data sharing, breaches of data security, or inadvertent data releases that may compromise data confidentiality within 24 hours of when the incident is identified. As permitted by law, notifications should include any known information regarding the incident and a general description of the activities or process in place to define and remediate the situation fully. Within 3 business days of the DAC notification(s), the Requester agrees to submit to the DAC(s) a detailed written report including the date and nature of the event, actions taken or to be taken to remediate the issue(s), and plans or processes developed to prevent further problems, including specific information on timelines anticipated for action. The Requester agrees to provide documentation verifying that the remediation plans have been implemented. Repeated violations or unresponsiveness to NIH requests may result in further compliance measures affecting the Requester. All notifications and written reports of data management incidents should be sent to the DAC(s) indicated in the Addendum to this Agreement. NIH, or another entity designated by NIH may, as permitted by law, also investigate any data security incident or policy violation. Approved Users and their associates agree to support such investigations and provide information, within the limits of applicable local, state, tribal, and federal laws and regulations. In addition, Requester and Approved Users agree to work with the NIH to assure that plans and procedures that are developed to address identified problems are mutually acceptable and consistent with applicable law.
