Temporary Space Upon reasonable prior notice from Tenant to Landlord, Landlord agrees to provide Tenant with temporary space (the "Temporary Space") on either the second floor of Building A or the second floor of Building B of a size and in a location to be mutually agreed upon by Landlord and Tenant for a period of time commencing no earlier than sixty (60) days from the date of Tenant's notice requesting that the Temporary Space be made available and expiring on the Commencement Date of this Lease. Tenant's occupancy of the Temporary Space shall be subject to all of the terms and conditions of this Lease to the extent appropriate, except that (i) Annual Fixed Rent for the Temporary Space shall be payable at the annual rate equal to the product of (x) $4.00 and (y) the rentable floor area of the Temporary Space, (ii) for the purposes of determining Tenant's payments on account of Landlord's Operating Expenses under Section 2.6 above and Landlord's Tax Expenses under Section 2.7 with respect to the Temporary Space, the "Rentable Floor Area of the Premises" shall be deemed to be the rentable floor area of the Temporary Space and (iii) the Temporary Space shall be delivered to Tenant in its "as is" condition and no improvement allowance or brokerage commission shall be payable with respect thereto. In addition, it is acknowledged and agreed that if Tenant shall elect to lease any Temporary Space hereunder, Tenant shall be occupying such Temporary Space while Landlord is proceeding with components of the Base Building Work in Buildings A and B and accordingly that Tenant shall use and occupy the Temporary Space in such as manner as to minimize any unreasonable interference with Landlord's performance of the Base Building Work. (signatures on next page) EXECUTED as a sealed instrument in two or more counterparts each of which shall be deemed to be an original. WITNESS: LANDLORD: BOSTON PROPERTIES LIMITED PARTNERSHIP By: Boston Properties, Inc., its general partner By: --/s/ Xxxxx RosenName: Xxxxx RosenTitle: Senior Vice President, Development TENANT ATTEST: By: By: /s/ Xxxxx Xxxxx Name: Name: Xxxxx Xxxxx Title: Secretary or Assistant Secretary Title: President or Vice President Hereto duly authorized By: Name: Title: Treasurer or Assistant Treasurer Hereto duly authorized EXHIBIT A DESCRIPTION OF SITE Those certain parcels of land (with the buildings thereon) situated in Bedford, Middlesex County, Massachusetts bounded and described as follows: PARCELS 1 and 2 Two certain parcels of land situated in Bedford, Middlesex County, Massachusetts, shown as Lot 1 and 2 on a plan entitled “Plan of Land in Bedford, Mass." dated March 1, 1962 by Xxxxxxx X. Xxxxxxx, Inc., recorded with Middlesex South District Deeds as Plan No. 487 of 1962 in Book 10022, Page 278, and together bound and described as follows: SOUTHWESTERLY by Xxxxxx Road by three lines measuring respectively two hundred eighty-three and 011100 (283.01) feet, twenty-one and 271100 (21.27) feet and four hundred eighty-three and 43/100 (483.43) feet; thence SOUTHERLY by said Xxxxxx Road by a curved line, one hundred nineteen and361100 (119.36) feet; thence SOUTHEASTERLY SOUTHERLY and SOUTHWESTERLY by said Xxxxxx Road by several lines measuring respectively two hundred ninety-three and 04/100 (293.04) feet, three hundred fifty three and 041100 (353.04) feet and two hundred twenty and 97/100 (220.97) feet; thence NORTHEASTERLY by the parcel marked "Reserved for Town of Bedford" on said plan, sixteen hundred forty-six and 81/100 (1646.81) feet; and thence NORTHWESTERLY by land now or late of The Worcester Corp., by two lines measuring respectively 305.23 feet and 294.24 feet and by land now or late of Xxxxxxx by two lines measuring respectively 170.33 feet and 64.34 feet, to the place of beginning. For Title see Deed recorded with the Middlesex South District Registry of Deeds in Book 12926, Page 233. PARCEL 3 A certain parcel of land situated in said Bedford, shown on a plan of land in Bedford, Mass.Dated June 5, 1961 by Xxxxxxx X. Xxxxxxx, Inc., Registered Land Surveyors, recorded with Middlesex South District Registry of Deeds at the end of Book 9844, bounded and described as follow: SOUTHWESTERLY by Xxxxxx Road, two hundred ninety-eight and 63/100 (298.63) feet; NORTHWESTERLY by land now or formerly of the Worcester Corporation, two hundred nine and 95/100 (209.95) feet; NORTHEASTERLY by land now or formerly of the Worcester Corporation, two hundred fifty and 57/100 (250.57) feet; and SOUTHEASTERLY by land now or formerly of Sinbad Realty Corporation by two lines respectively measuring one hundred seventy and 33/100 (170.33) feet and sixty-four and 341100(64.34) feet. Containing approximately 60,951 square feet of 1.4 acres according to said plan. For Title see Deed from Xxxxx X. Xxxxxxx and Xxxxxxxxx X. Xxxxxxx recorded with the Middlesex South District Registry of Deeds in Book 13539, Page 732. PARCEL 4 All right, title and interest in and to (i) that portion of Xxxxxx Road described in that certain Deed (a) recorded with the Middlesex South District Registry of Deeds in Book 14013, Page 486 and (b) filed with the Middlesex South Registry District of the Land Court as Document No. 599584 as to which Certificate of Title No. 161163 in Registration Book 936, Page 13 was issued; and
Generator Subject to the provisions of this Section 29.36, Tenant shall be entitled to install, operate and maintain a generator and any other equipment related thereto, including, without limitation, a fuel system, wiring and shaft space (“Generator”) next to the Building at Tenant’s sole cost and expense (without paying any additional fee or rental to Landlord for the use thereof). Prior to the installation of the Generator, Tenant shall inspect the proposed location to determine a suitable location for the Generator, and Tenant shall submit written plans and specifications relative to the type, size and proposed location (including any proposed screening) of the Generator to Landlord for its review and written approval. Tenant shall be solely responsible for the cost of acquisition, installation, operation, and maintenance of the Generator; and Tenant shall install, maintain and operate the Generator in accordance with all federal, state, and local laws, statutes, ordinances, rules and regulations, including without limitation, obtaining and maintaining any and all permits, approvals and licenses required to install and operate the Generator by any governmental authority having jurisdiction. Landlord and Tenant agree that, upon the expiration of earlier termination of the Lease Term, Tenant shall not be required to remove the Generator, any associated cabling, wiring and screening or other improvements. Tenant shall not be entitled to grant or assign to any third party (other than a permitted assignee of Tenant’s rights under the Lease or a permitted subtenant relative to the Premises (or a portion thereof)) the right to use the Generator without Landlord’s prior written consent (which consent may be granted or withheld in Landlord’s discretion). Upon reasonable advance notice to Tenant (and provided Landlord reasonably coordinates with Tenant and provides an alternate source of backup generator capacity during said transition), Landlord shall be entitled to cause the Generator to be moved to another location near the Building, at Landlord’s cost and expense. Tenant shall pay all personal property taxes on the Generator. Tenant shall also pay any increases in the real property taxes of the Building due to the installation of the Generator within thirty (30) days of receipt of notice from Landlord which includes proof of such increase in taxes. Tenant’s indemnity obligations under Section 5.4.1.5 of the Lease, relating to the use of Hazardous Materials, shall apply to the use and operation of the Generator. Finally, Tenant’s insurance obligations under Section 10.3 of the Lease shall apply to the Generator.
Temporary Taking If the whole or any part of the Leased Property (other than the fee) or of Lessee’s interest under this Lease is condemned by any Condemnor for its temporary use or occupancy (which shall mean a period not to exceed two years), this Lease shall not terminate by reason thereof, and Lessee shall continue to pay, in the manner and at the terms herein specified, the full amounts of Base Rent and Additional Charges. In addition, Lessee shall pay Percentage Rent at a rate equal to the average Percentage Rent during the last three (3) preceding Fiscal Years (or if three (3) Fiscal Years shall not have elapsed, the average during the preceding Fiscal Years). Except only to the extent that Lessee may be prevented from so doing pursuant to the terms of the order of the Condemnor, Lessee shall continue to perform and observe all of the other terms, covenants, conditions and obligations hereof on the part of Lessee to be performed and observed, as though such Condemnation had not occurred. In the event of any Condemnation as in this Section 15.6 described, the entire amount of any Award made for such Condemnation allocable to the Term of this Lease, whether paid by way of damages, rent or otherwise, shall be paid to Lessee. Lessee covenants that upon the termination of any such period of temporary use or occupancy it will, at its sole cost and expense (subject to Lessor’s contribution as set forth below), restore the Leased Property as nearly as may be reasonably possible to the condition in which the same was immediately prior to such Condemnation, unless such period of temporary use or occupancy extends beyond the expiration of the Term, in which case Lessee shall not be required to make such restoration. If restoration is required hereunder, Lessor shall contribute to the cost of such restoration that portion of its entire Award that is specifically allocated to such restoration in the judgment or order of the court, if any, and Lessee shall fund the balance of such costs in a manner reasonably satisfactory to Lessor.
Emergency Generator Tenant shall have the right to tie into and use the emergency generator to be installed by Landlord as part of the Base Building Work for use by tenants of the Unit (the “Unit Generator”). Tenant shall be responsible, at its sole cost and expense, for installing, maintaining, repairing and replacing its connection between the Premises and the Unit Generator, and all associated cabling. Tenant shall be permitted to use up to an average of three (3) xxxxx per square foot of usable area in the Premises from the Unit Generator, and at no time shall Tenant exceed that use limitation with respect to the Unit Generator. Except to the extent that Tenant ties into the Unit Generator as part of the Initial Tenant Work in accordance with the provisions of the Work Letter, installation of such tie-in and any related cabling, conduit and appurtenances will be governed by the applicable provisions of this Lease relating to Tenant Work. Tenant will submit to Landlord at least thirty (30) days prior to the proposed installation date Tenant’s proposed plans and specifications relating to the tie-in to the Unit Generator and all associated lines. Tenant may not commence any work to tie into the Unit Generator until it has received Landlord’s prior written approval (not to be unreasonably withheld, delayed or conditioned) of such plans and specifications. Tenant, at its sole cost and expense, shall comply with all applicable Legal Requirements and Title Matters and Landlord’s reasonable directives relating to the installation, operation, maintenance and repair of such tie-in, including (i) obtaining and maintaining (or causing to be obtained and maintained) and complying with the provisions of all applicable permits relating to the tie into and use of the Unit Generator. Tenant may not use the Unit Generator for any purpose other than solely in connection with Tenant’s occupancy of the Premises for the Permitted Use and in accordance with any applicable permit(s) pertaining to the Unit Generator. Except for permitted subtenants and assignees. Tenant may not use the Unit Generator to serve other occupant(s) of the Development.
Floor Loading Floor loading capacity shall be within building design capacity. Tenant may exceed floor loading capacity with Landlord’s consent, at Landlord’s sole discretion and must, at Tenant’s sole cost and expense, reinforce the floor as required for such excess loading.
Temporary Securities Pending the preparation of definitive Securities of any series, the Company may execute, and upon Company Order the Trustee shall authenticate and deliver, temporary Securities which are printed, lithographed, typewritten, mimeographed or otherwise produced, in any authorized denomination, substantially of the tenor of the definitive Securities in lieu of which they are issued and with such appropriate insertions, omissions, substitutions and other variations as the officers executing such Securities may determine, as evidenced by their execution of such Securities. If temporary Securities of any series are issued, the Company will cause definitive Securities of that series to be prepared without unreasonable delay. After the preparation of definitive Securities of such series, the temporary Securities of such series shall be exchangeable for definitive Securities of such series upon surrender of the temporary Securities of such series at the office or agency of the Company in a Place of Payment for that series, without charge to the Holder. Upon surrender for cancellation of any one or more temporary Securities of any series, the Company shall execute and the Trustee shall authenticate and deliver in exchange therefor one or more definitive Securities of the same series, of any authorized denominations and of like tenor and aggregate principal amount. Until so exchanged, the temporary Securities of any series shall in all respects be entitled to the same benefits under this Indenture as definitive Securities of such series and tenor.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Temporary Global Notes Notes offered and sold in reliance on Regulation S shall be issued initially in the form of the Regulation S Temporary Global Note, which shall be deposited on behalf of the purchasers of the Notes represented thereby with the Trustee, at its New York office, as custodian for the Depositary, and registered in the name of the Depositary or the nominee of the Depositary for the accounts of designated agents holding on behalf of Euroclear or Cedel Bank, duly executed by the Company and authenticated by the Trustee as hereinafter provided. The Restricted Period shall be terminated upon the receipt by the Trustee of (i) a written certificate from the Depositary, together with copies of certificates from Euroclear and Cedel Bank certifying that they have received certification of non-United States beneficial ownership of 100% of the aggregate principal amount of the Regulation S Temporary Global Note (except to the extent of any beneficial owners thereof who acquired an interest therein during the Restricted Period pursuant to another exemption from registration under the Securities Act and who will take delivery of a beneficial ownership interest in a 144A Global Note or an IAI Global Note bearing a Private Placement Legend, all as contemplated by Section 2.06(a)(ii) hereof), and (ii) an Officers' Certificate from the Company. Following the termination of the Restricted Period, beneficial interests in the Regulation S Temporary Global Note shall be exchanged for beneficial interests in Regulation S Permanent Global Notes pursuant to the Applicable Procedures. Simultaneously with the authentication of Regulation S Permanent Global Notes, the Trustee shall cancel the Regulation S Temporary Global Note. The aggregate principal amount of the Regulation S Temporary Global Note and the Regulation S Permanent Global Notes may from time to time be increased or decreased by adjustments made on the records of the Trustee and the Depositary or its nominee, as the case may be, in connection with transfers of interest as hereinafter provided.
Floor Load Tenant shall not place a load upon any floor of the Premises that exceeds 50 pounds per square foot “live load”. Landlord reserves the right to reasonably designate the position of all Equipment which Tenant wishes to place within the Premises, and to place limitations on the weight thereof.
Temporary Certificates (a) Pending the preparation of definitive Certificates, upon the order of the Depositor, the Trustee shall execute and shall authenticate and deliver temporary Certificates that are printed, lithographed, typewritten, mimeographed or otherwise produced, in any authorized denomination, substantially of the tenor of the definitive Certificates in lieu of which they are issued and with such variations as the authorized officers executing such Certificates may determine, as evidenced by their execution of such Certificates.
