Temporary Suspension or Delay of Performance of Contract Sample Clauses

Temporary Suspension or Delay of Performance of Contract. To the extent that it does not alter the scope of this agreement, Augusta, GA may unilaterally order a temporary stopping of the work, or delaying of the work to be performed by CONSULTANT under this agreement.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Temporary Suspension or Delay of Performance of Contract. To the extent that it does not alter the scope of this Contract the Owner may unilaterally order a temporary stopping of the work or delaying of the work to be performed by the Contractor under this Contact.
Sample 1Sample 2See All (5)
Temporary Suspension or Delay of Performance of Contract. To the extent that it does not alter the scope of this Agreement, Augusta Georgia may unliterally order a temporary stopping of the work, or delaying of the work to be performed by Consultant under this Agreement.
Sample 1Sample 2See All (4)

Related to Temporary Suspension or Delay of Performance of Contract

  • Suspension of Performance Notwithstanding any other provision hereof, if an Event of Default or a Potential Event of Default has occurred and is continuing, the Non-Defaulting Party, upon written notice to the Defaulting Party, has the right (i) to suspend performance under any or all Transactions and (ii) to the extent an Event of Default has occurred and is continuing, to exercise any remedy available at law or in equity, except as limited be Section 5.7.

  • Suspension of Performance or Disbursement Into Court If, at any time, (i) there shall exist any dispute between Broker, Issuer, NCPS, any Subscriber or any other person with respect to the holding or disposition of all or any portion of the Escrow Funds or any other obligations of NCPS hereunder, or (ii) if at any time NCPS is unable to determine, to NCPS’s reasonable satisfaction, the proper disposition of all or any portion of the Escrow Funds or NCPS’s proper actions with respect to its obligations hereunder, or (iii) if Broker and Issuer have not within 30 days of the furnishing by NCPS of a notice of resignation pursuant to Section 7 hereof appointed a successor NCPS to act hereunder, then NCPS may, in its reasonable discretion, take either or both of the following actions: a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of NCPS or until a successor NCPS shall have been appointed (as the case may be). b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to NCPS, for instructions with respect to such dispute or uncertainty, and to the extent required or permitted by law, pay into such court all funds held by it in the Escrow Funds for holding and disposition in accordance with the instructions of such court. NCPS shall have no liability to Broker, Issuer, any Subscriber or any other person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of the Escrow Funds or any delay in or with respect to any other action required or requested of NCPS.

  • Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!