Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Storage Space (a) In addition to the Premises defined in Section 1.2 above, Landlord desires to lease to Tenant and Tenant desires to lease from Landlord additional space comprising approximately Five Hundred Fifty-Nine (559) rentable square feet of below grade space in the Building as shown on Exhibit A-3 attached hereto (hereinafter referred to as the "Storage Space"), on the all of the terms and conditions of the Lease applicable to the Premises except as specifically set forth in this Paragraph 13.
(b) Tenant shall pay to Landlord Ten and No/100 Dollars ($10.00) per rentable square foot of space in the Storage Space with respect to the Storage Space throughout the Term of the Lease. Such monthly installments of storage rent shall hereinafter be referred to as "Monthly Storage Space Rent". The Monthly Storage Space Rent will constitute Additional Rent (as defined in the Lease) and shall be due and payable, without deduction or set off, on the first (1st) day of each calendar month during the Term of the Lease commencing January 1, 2005. Tenant's obligation to pay Monthly Storage Space Rent hereunder shall be abated from the period commencing on the Commencement Date and continuing until December 31, 2004. No other amounts other than Monthly Storage Space Rent shall be abated except as expressly provided elsewhere in the Lease. If Tenant defaults under the Lease after the expiration of any applicable notice and cure period prior to January 1, 2005, then Tenant shall no longer be entitled to any further abatement of Monthly Storage Space Rent. Monthly Storage Space Rent for any period during the term hereof which is for less than one (1) month shall be prorated based upon the actual number of days of the calendar month involved.
(c) Notwithstanding anything to the contrary contained in the Lease or herein, (i) the Base Rent payable with respect to the Premises set forth in Section 1.8 of the Lease shall not be applicable to the Storage Space; (ii) Monthly Storage Space Rent payable with respect to the Storage Space shall not be subject to annual escalations; (iii) neither Operating Expense increases as set forth in Section 5 of the Lease nor the Electric Energy Charge as set forth in Section 11.6 of the Lease shall be payable with respect to the Storage Space.
(d) Tenant shall use the Premises solely for storage of office supplies, files, UPS battery packs and product samples and for no other purposes whatsoever.
(e) All property placed in the Storage Space by Tenant, its agents, or any other persons, shall be and remain at the sole risk of Tenant, its agents or other persons. Landlord shall not be liable for any damage to, or theft or loss of, such property, whether or not caused by the act or omission of any person, including Landlord or its agent, or by the bursting, leaking or overflowing of water, sewer or sprinkler pipes, plumbing fixtures, or any other act or thing, unless such damage to, or theft or loss of, such property results directly from the negligence or willful misconduct of Landlord and then only to the extent that Tenant, its agents or any other persons, are not compensated therefor by Tenant's insurance. In no event shall Landlord or its agent be liable for consequential damages.
(f) Landlord shall deliver the Storage Space with full height walls, sprinklers, appropriate lighting and a secure locked door. Except as specifically provided herein, Tenant hereby agrees to accept the Storage Space in its "as is" condition existing on the Commencement Date and Landlord shall have no obligation to construct any tenant improvements to the Storage Space on behalf of Tenant. Tenant is not entitled to any improvement allowance pursuant to the terms of the Lease. Landlord will not provide heat, air conditioning, water, char service or any other utility or service to the Premises and the provisions of Section 11 of the Lease shall not apply to the Storage Space.
(g) Notwithstanding any provision herein or in the Lease to the contrary, the Storage Space shall not be counted in connection with, or applied to, the calculation of Tenant's Share set forth in Section 1.11 of the Lease nor the calculation of the number of parking spaces Landlord shall allocate to Tenant pursuant to Section 1.13
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter:
a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications).
b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows:
(i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and
(ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises.
c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements:
(a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work.
(b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay.
(c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord.
(d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Landlord Work Prior to the execution of this First Amendment, Landlord and Tenant have approved (i) a detailed space plan for the construction of Landlord’s Work in the Premises, which space plan has been prepared by Studio O + A (“Final Approved Plan”) and (ii) a bid proposal for the construction of Landlord’s Work in the Premises, which bid proposal has been prepared by XX Xxxx Construction and is dated June 2, 2011 (Rev-2) (“Bid Proposal”). The Final Approved Plan and Bid Proposal are approved by the parties as of the Effective Date, are attached hereto collectively, as Exhibit “D-1” and hereby replaces the original Approved Plan attached to the Lease as Exhibit “D-1”. Consequently, all references in the Work Letter to the “Approved Plan” shall mean and refer to the Final Approved Plan and Bid Proposal attached hereto as Exhibit “D-1”. Landlord agrees to construct the Landlord Work, pursuant to the terms and conditions set forth in the Work Letter and as depicted on the Approved Plan (as amended hereby). Landlord shall pay for the cost (including, the cost of obtaining all applicable building permits) of the design and construction of Landlord’s Work in an amount up to, but not exceeding, Two Hundred Twenty Two Thousand One Hundred Fifty and 00/100 Dollars ($222,150.00) plus any additional costs actually incurred by Landlord in excess of such $222,150.00 amount as a direct result of Landlord’s or Landlord’s contractor’s active negligence or willful misconduct or resulting from change order to the Approved Plans (as amended hereby) if such change order is initiated and executed by Landlord (the “Landlord’s Contribution”). Tenant shall pay for all costs in excess of the Landlord’s Contribution (“Over Allowance Amount”) which payment shall be made to Landlord in cash within thirty (30) days after Tenant’s receipt of invoice therefor from Landlord. Payment of the Over-Allowance Amount shall be in addition to Tenant’s obligation to pay to Landlord the cost of any Aggregate Extras as provided in Section 4 of the Work Letter.
Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.
Landlord’s Work The Landlord will provide and carry out, in accordance with the provisions of the Lease, including, without limitation, this Schedule, at the Tenant’s expense, all equipment and work other than Tenant’s Work required to be provided in order to render the Premises complete and suitable to open for business (the “Landlord’s Work”) including, but not limited to the following: • Connecting all utilities including, power to building and distribution panels to the Premises, including the requirement to provide via separate metering. • Connecting water, including without limitation hot water, to greenhouse area and distribution water tank(s). • Installation of a storage cooler. • All concrete work around the greenhouse and drive-way to the compost hut and floor for compost piles as designed. • Installation of necessary or required ventilation fans. • Installation or replacement of lighting, including without limitation any required high upper grow lights. • Installation of hand wash stations in the Premises. • Gas heaters and controls. • Any repairs or refurbishing of outer panels, germination room walls. The Tenant’s consent (not to be unreasonably withheld, conditioned or delayed), shall be required prior to the commencement of the Landlord’s Work. The Landlord shall provide, in such detail as the Tenant may reasonably request, all material documentation relating to the Landlord’s Work, including without limitation, any proposed plans and drawings, proposed agreements with any contractors or subcontractors and estimated costs to complete the Landlord’s Work. Subject to receiving the Tenant’s consent as contemplated herein, the Landlord shall commence the Landlord’s Work in accordance with the terms of this Lease. Upon completion of the Landlord’s Work, the Landlord shall provide the Tenant receipted invoices verifying the actual cost of completing the Landlord’s Work in the Premises. It is acknowledged and agreed that in consideration for the Tenant being responsible for all the costs associated with the Landlord’s Work as contemplated herein, the cost of the Landlord’s Work shall be included in total amount subject recoverable by the Tenant and to the Free Rent Period (as hereinafter defined) subject to the terms and conditions of this Schedule “D” and the Lease, generally.
Expansion Premises (a) In consideration of the rents, terms, provisions and covenants of this Amendment and the Lease, Landlord hereby leases unto Tenant and Tenant hereby rents and accepts from Landlord the Expansion Premises. The Expansion Premises is more particularly described on Exhibit A attached hereto. The Expansion Premises is contiguous to the Replacement Premises.
(b) Tenant covenants, as a material part of the consideration for the Lease, as amended hereby, to keep and perform each and all of said terms, covenants and conditions for which Tenant is liable and that this Amendment is made upon the condition of such performance. On and after the Second Renewal Term Commencement Date, all of the terms and provisions of the Lease, as amended hereby, shall apply to both the Replacement Premises and the Expansion Premises. From and after the Second Renewal Term Commencement Date, each and every reference in the Lease and in this Amendment to “Premises” shall be and mean the Replacement Premises and the Expansion Premises, collectively. The Replacement Premises and Expansion Premises consist of a total of approximately 12,103 rentable square feet. The Expansion Premises shall be known as Suite 246.
(c) At Landlord’s request, Tenant shall execute a Commencement Date Memorandum in the form attached hereto as Exhibit B acknowledging, among other things, the (i) Second Renewal Term Commencement Date, (ii) scheduled termination date of the Lease and (iii) Tenant’s acceptance of the Expansion Premises. Tenant’s failure to execute the Commencement Date Memorandum shall not affect Tenant’s liability hereunder.
