Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Tenant’s Default 14.1 Any other provisions in this Lease notwithstanding, it shall be an event of default (“Event of Default”) under this Lease if: (i) Tenant fails to pay any installment of rent or any other sum payable by Tenant hereunder when due and such failure continues for a period of ten (10) days after written notice from Landlord to Tenant that such payment has not been received, or (ii) Tenant fails to observe or perform any other material covenant or agreement of Tenant herein contained and such failure continues after written notice given by or on behalf of Landlord to Tenant for more than thirty (30) days, provided, however, that if such non-monetary Event of Default by Tenant cannot reasonably be cured within such thirty (30) day period, and provided further that Tenant is proceeding with due diligence to effect a cure of said Event of Default, no Event of Default hereunder shall be declared by Landlord if Tenant continues to proceed with diligence to cure said Event of Default, but in no event shall such cure period extend beyond ninety (90) days following notice from Landlord of such violation, default or breach, or (iii) Tenant files a petition commencing a voluntary case, or has filed against it a petition commencing an involuntary case, under the Federal Bankruptcy Code (Title 11 of the United States Code), as now or hereafter in effect, or under any similar law, or files or has filed against it a petition or answer in bankruptcy or for reorganization or for an arrangement pursuant to any state bankruptcy law or any similar state law, and, in the case of any such involuntary action, such action shall not be dismissed, discharged or denied within sixty (60) days after the filing thereof, or Tenant consents or acquiesces in the filing thereof, or (iv) a custodian, receiver, trustee or liquidator of Tenant or of all or substantially all of Tenant’s property or of the Premises shall be appointed in any proceedings brought by or against Tenant and, in the latter case, such entity shall not be discharged within sixty (60) days after such appointment or Tenant consents to or acquiesces in such appointment, or (v) Tenant shall generally not pay Tenant’s debts as such debts become due, or shall make an assignment for the benefit of creditors, or shall admit in writing its inability to pay its debts generally as they become due. The notice and grace period provisions in clauses (i) and (ii) above shall have no application to the Events of Default referred to in clauses (iii) through (v) above.
TENANT’S DEFAULTS In addition to any other event of default set forth in this Lease, the occurrence of any one or more of the following events shall constitute a default by Tenant:
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Owner Default Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: This bond is subject to the attached Dual Obligee Rider dated [ ]. (Space is provided below for additional signatures of added parties other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY (Corporate Seal) (Corporate Seal) Company: Company: Address: Address: Name and Title: Name and Title: Signature: Signature: (TO BE ATTACHED TO BOND AT TIME OF ISSUANCE) TO BE ATTACHED TO AND FORM PART OF Performance and Payment Bond NO. ___, dated concurrently with the execution of this Rider, issued by the ___, a ___corporation, as Surety, on behalf of Fxxxx, Inc., as Principal, and in favor of ___, as Obligee. IT IS HEREBY UNDERSTOOD AND AGREED that the above described bond(s) are hereby amended to include the following paragraph: Notwithstanding anything contained herein to the contrary, there shall be no liability on the part of the Principal or Surety under this bond to the Obligees, or either of them, unless the Obligees, or either of them, shall make payments to the Principal or to the Surety in case it arranges for completion of the Contract upon default of the Principal, strictly in accordance with the terms of said Contract as to payments, and shall perform all the other obligations required to be performed under said Contract at the time and in the manner therein set forth. IT IS FURTHER UNDERSTOOD AND AGREED that nothing herein contained shall be held to change, alter or vary the terms of the above described bond(s) except as hereinbefore set forth. SIGNED, SEALED AND DATED this ___day of ___, 200_. Fxxxx, Inc. (Contractor) [Name of Project Company] ___ ___,2006 By: [ ] (Surety) By: [Name of Project Company] ___ ___,2006 EXHIBIT J Draw (Payment) Schedule MONTH BILLING TOTAL BILLING 1 $ $ % 2 $ $ % 3 $ $ % 4 $ $ % 5 $ $ % 6 $ $ % 7 $ $ % 8 $ $ % 9 $ $ % 10 $ $ % 11 $ $ % 12 $ $ % 13 $ $ % 14 $ $ % 15 $ $ % 16 $ $ % $[Price] [Name of Project Company] ___ ___,2006 EXHIBIT K Air Emissions Application or Permit [Name of Project Company] ___ ___,2006 EXHIBIT L Phase I and Phase II Engineering Services Agreement [Name of Project Company] ___ ___,2006 L-1 EXHIBIT M Form of Application for Payment [Name of Project Company] ___ ___,2006 M-1 EXHIBIT N Form of Lien Waiver GENERAL CONTRACTOR’S PARTIAL WAIVER OF MECHANIC’S LIEN RIGHTS AND AFFIDAVIT OF DEBTS AND CLAIMS CONDITIONAL LIEN WAIVER STATE: ( INSERT STATE ) FXXXX, INC. COUNTY: ( INSERT COUNTY ) The undersigned is the General Contractor (aka Design-Builder) regarding labor and materials for construction and maintenance work performed for ( INSERT OWNER/PLANT NAME ), at the Facility located at or near ( INSERT PLANT CITY & STATE ) under the terms of a contract. On condition of receiving full payment for bxxxxxxx up to date hereof under the terms of the above mentioned contract, and other good and valuable consideration, the receipt of which is hereby acknowledged, the undersigned does hereby waive and release any and all liens, and any and all claims and rights to lien on the Facility (including all buildings on the premises) under the statutes of the State of ( INSERT STATE ) relating to mechanic’s liens on account of labor and materials furnished by the undersigned up to the date hereof at the Facility, as located on real estate legally described as follows: TRACT 1: ( INSERT LEGAL DESCRIPTION ) TRACT 2: ( INSERT LEGAL DESCRIPTION ) [Name of Project Company] ___ ___,2006 N-1 The undersigned further certifies that all obligations of General Contractor entered into between suppliers/subcontractors and General Contractor regarding this Facility are current as of this date, including all obligations of General Contractor for all work, labor and services performed; materials and equipment furnished; and all known indebtedness and claims against General Contractor for damages arising in any manner in connection with General Contractor’s performance of the contract mentioned above for which General Contractor or property of General Contractor might in any way be held responsible. Dated this ___day of ___, 200___ GENERAL CONTRACTOR: FXXXX, INC. By (Print): Title: (Signature): Witness (Print): (Signature): In the alternative (or if requested): Subscribed and sworn to before me this ___day of ___, 200___. Notary Public My Commission Expires: [Name of Project Company] ___ ___,2006 N-2 EXHIBIT O Form of Consent to Assignment [Name of Project Company] ___ ___,2006
LESSEE'S DEFAULT The occurrence of any one or more of the following events shall constitute a default and breach of this Lease by Lessee:
Reservation Default Failure by the Borrower to have reserve for issuance upon conversion of the Note the amount of Common stock as set forth in the Subscription Agreement.
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Upon Default Landlord shall have the right to pursue any one or more of the following remedies:
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
