Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Notice of Event of Default If the Mortgagee shall have Actual Knowledge of an Event of Default or of a Default arising from a failure to pay Rent, the Mortgagee shall give prompt written notice thereof to the Owner Trustee, the Owner Participant, Lessee, and each Note Holder. Subject to the terms of Sections 2.13, 4.03, 4.04, 4.08, 5.02 and 5.03 hereof, the Mortgagee shall take such action, or refrain from taking such action, with respect to such Event of Default or Default (including with respect to the exercise of any rights or remedies hereunder) as the Mortgagee shall be instructed in writing by a Majority in Interest of Note Holders. Subject to the provisions of Section 5.03, if the Mortgagee shall not have received instructions as above provided within 20 days after mailing notice of such Event of Default to the Note Holders, the Mortgagee may, subject to instructions thereafter received pursuant to the preceding provisions of this Section 5.01, take such action, or refrain from taking such action, but shall be under no duty to take or refrain from taking any action, with respect to such Event of Default or Default as it shall determine advisable in the best interests of the Note Holders; PROVIDED, HOWEVER, that the Mortgagee may not sell the Aircraft or any Engine without the consent of a Majority in Interest of Note Holders. For all purposes of this Trust Indenture, in the absence of Actual Knowledge on the part of the Mortgagee, the Owner Trustee or the Owner Participant, the Mortgagee, the Owner Trustee or the Owner Participant, as the case may be, shall not be deemed to have knowledge of a Default or an Event of Default (except, in the case of the Mortgagee, the failure of Lessee to pay any installment of Basic Rent within one Business Day after the same shall become due, if any portion of such installment was then required to be paid to the Mortgagee, which failure shall constitute knowledge of a Default) unless notified in writing by Lessee, the Owner Trustee, the Owner Participant or one or more Note Holders.
Landlord’s Right to Cure Tenant’s Default If an Event of Default shall have occurred and be continuing, Landlord, after Notice to Tenant (which Notice shall not be required if Landlord shall reasonably determine immediate action is necessary to protect person or property), without waiving or releasing any obligation of Tenant and without waiving or releasing any Event of Default, may (but shall not be obligated to), at any time thereafter, make such payment or perform such act for the account and at the expense of Tenant, and may, to the maximum extent permitted by law, enter upon the Leased Property or any portion thereof for such purpose and take all such action thereon as, in Landlord's sole and absolute discretion, may be necessary or appropriate therefor. No such entry shall be deemed an eviction of Tenant. All reasonable costs and expenses (including, without limitation, reasonable attorneys' fees) incurred by Landlord in connection therewith, together with interest thereon (to the extent permitted by law) at the Overdue Rate from the date such sums are paid by Landlord until repaid, shall be paid by Tenant to Landlord, on demand.
Notice to Landlord’s Mortgagee Tenant shall not seek to enforce any remedy it may have for any default on the part of Landlord without first giving written notice by certified mail, return receipt requested, specifying the default in reasonable detail, to any Landlord’s Mortgagee whose address has been given to Tenant, and affording such Landlord’s Mortgagee a reasonable opportunity to perform Landlord’s obligations hereunder.
Default of Tenant Provided and it is hereby expressly agreed that if and whenever the Annual Rent or Additional Rent hereby reserved or any part thereof shall not be paid on the day appointed for payment thereof, whether lawfully demanded or not, or in case of breach or non-observance or non-performance of any of the covenants, agreements, provisos, conditions or Rules and Regulations on the part of the Tenant to be kept, observed or performed, or in case the Leased Premises shall be vacated or remain unoccupied for fifteen (15) days or in case the Term shall be taken in execution or attachment for any cause whatever, then and in every such case, it shall be lawful for the Landlord thereafter to enter into and upon the Leased Premises or any part thereof in the name of the whole and the same to have again, repossess and enjoy as of its former estate, anything in this Lease contained to the contrary notwithstanding other than the proviso to this paragraph; PROVIDED that the Landlord shall not at any time have the right to re-enter and forfeit this Lease by reason of the Tenant's default in the payment of the rent reserved by this Lease, unless and until the Landlord shall have given to the Tenant written notice setting forth the default complained of and the Tenant shall have the right during five (5) business days next following the date on such notice to cure any such default in payment of rent. In case without the written consent of the Landlord, the Leased Premises shall be used by any other person than the Tenant or for any other purpose than that for which the same were let or in case the Term or any of the goods and chattels of the Tenant shall be at any time seized in execution or attachment by any creditor of the Tenant or if the Tenant makes any bulk sale, then in any such case this lease shall, at the option of the Landlord, cease and determine and the Term shall immediately become forfeited and void in accordance with the provisions of Section 15, RIGHT OF TERMINATION, herein.
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
Tenant Estoppel Certificate Please refer to the documents described in Schedule 1 hereto, (the “Lease Documents”) including the “Lease” therein described; all defined terms in this Certificate shall have the same meanings as set forth in the Lease unless otherwise expressly set forth herein. The undersigned Tenant hereby certifies that it is the tenant under the Lease. Tenant hereby further acknowledges that it has been advised that the Lease may be collaterally assigned in connection with a proposed financing secured by the Property and/or may be assigned in connection with a sale of the Property and certifies both to Landlord and to any and all prospective mortgagees and purchasers of the Property, including any trustee on behalf of any holders of notes or other similar instruments, any holders from time to time of such notes or other instruments, and their respective successors and assigns (the “Beneficiaries”) that as of the date hereof:
