Termination by Company The Company is authorized to terminate this Fee Agreement at any time with respect to all or part of the Project upon providing the County with thirty (30) days’ written notice; provided, however, that (i) any monetary obligations existing hereunder and due and owing at the time of termination to a party hereto (including without limitation any amounts owed with respect to Section 4.03 hereof); and (ii) any provisions which are intended to survive termination shall survive such termination. In the year following such termination, all property shall be subject to ad valorem taxation or such other taxation or fee in lieu of taxation that would apply absent this Fee Agreement. The Company’s obligation to make FILOT Payments under this Fee Agreement shall terminate in the year following the year of such termination pursuant to this section.
Termination by Company for Cause Subject to Section 3.2, the Company may terminate Employee’s employment and all of the Company’s obligations under this Agreement at any time “For Cause” (as defined below) by giving notice to Employee stating the basis for such termination, effective immediately upon giving such notice or at such other time thereafter as the Company may designate. “For Cause” shall mean any of the following: (i) Employee’s willful and continued failure to substantially perform the reasonably assigned duties with the Company which are consistent with Employee’s position and job description referred to in this Agreement, other than any such failure resulting from incapacity due to physical or mental illness, after a written notice is delivered to Employee by the Board of Directors of the Company which specifically identifies the manner in which Employee has not substantially performed the assigned duties and allowing Employee thirty (30) days after receipt by Employee of such notice to cure such failure to perform, (ii) material breach of this or any other written agreement between Employee and the Company which is not cured within thirty (30) days after receipt by the Employee from the Company of written notice of such breach, (iii) any material violation of any written policy of the Company which is not cured within thirty (30) days after receipt by Employee from the Company of written notice of such violation, (iv) Employee’s willful misconduct which is materially and demonstrably injurious to the Company, (v) Employee’s conviction by a court of competent jurisdiction of, or his pleading guilty or nolo contendere to, any felony, or (vi) Employee’s commission of an act of fraud, embezzlement, or misappropriation against the Company or any breach of fiduciary duty or breach of the duty of loyalty, including, but not limited to, the offer, payment, solicitation or acceptance of any unlawful bribe or kickback with respect to the Company’s business. For purposes of this paragraph, no act, or failure to act, on Employee’s part shall be considered “willful” unless done, or omitted to be done, in knowing bad faith and without reasonable belief that the action or omission was in, or not opposed to, the best interests of the Company. Any act, or failure to act, expressly authorized by a resolution duly adopted by the Board of Directors or based upon the written advice of counsel for the Company shall be conclusively presumed to be done, or omitted to be done, in good faith and in the best interests of the Company. Notwithstanding the foregoing, Employee shall not be deemed to have been terminated For Cause unless and until there shall have been delivered to Employee a copy of a resolution, duly adopted by the Board of Directors at a meeting of the Board called and held for such purpose (after reasonable notice to Employee and an opportunity for Employee, together with Employee’s counsel, to be heard before the Board), finding that in the good faith opinion of the Board of Directors Employee committed the conduct set forth above in (i), (ii), (iii), (iv), (v) or (vi) of this Section and specifying the particulars thereof in detail.
Termination by CAISO Subject to Section 5.2, the CAISO may terminate this Agreement by giving written notice of termination in the event that the Participating Load commits any material default under this Agreement and/or the CAISO Tariff which, if capable of being remedied, is not remedied within thirty (30) days after the CAISO has given, to the Participating Load, written notice of the default, unless excused by reason of Uncontrollable Forces in accordance with Article X of this Agreement. With respect to any notice of termination given pursuant to this Section, the CAISO must file a timely notice of termination with FERC, if this Agreement was filed with FERC, or must otherwise comply with the requirements of FERC Order No. 2001 and related FERC orders. The filing of the notice of termination by the CAISO with FERC will be considered timely if: (1) the filing of the notice of termination is made after the preconditions for termination have been met, and the CAISO files the notice of termination within sixty (60) days after issuance of the notice of default; or (2) the CAISO files the notice of termination in accordance with the requirements of FERC Order No. 2001. This Agreement shall terminate upon acceptance by FERC of such a notice of termination, if filed with FERC, or thirty (30) days after the date of the CAISO’s notice of default, if terminated in accordance with the requirements of FERC Order No. 2001 and related FERC orders.
Termination by City City reserves the right to terminate this Agreement at any time, with or without cause, upon written notice to Consultant. Upon receipt of any notice of termination from City, Consultant shall immediately cease all services hereunder except such as may be specifically approved in writing by City. Consultant shall be entitled to compensation for all services rendered prior to receipt of City's notice of termination and for any services authorized in writing by City thereafter. If termination is due to the failure of Consultant to fulfill its obligations under this Agreement, City may take over the work and prosecute the same to completion by contract or otherwise, and Consultant shall be liable to the extent that the total cost for completion of the services required hereunder, including costs incurred by City in retaining a replacement consultant and similar expenses, exceeds the Budget.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice.
§ 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination.
§ 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause.
§ 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements.
§ 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
Term Suspension and Termination 9.1. Term of this MSA. This MSA comes into force on the date you first accept it by whatever means and continues until all Subscriptions expire or have been terminated.
TERMINATION BY MPS MPS further reserves the right to terminate this Contract at any time for any reason by giving Contractor written notice by Registered or Certified Mail of such termination. MPS will attempt to give Contractor 20 days’ notice, but reserves the right to give immediate notice. In the event of said termination, Contractor shall reduce its activities hereunder, as mutually agreed to, upon receipt of said notice. Upon said termination, Contractor shall be paid for all services rendered through the date of termination, including any retainage. This section also applies should the Milwaukee Board of School Directors fail to appropriate additional monies required for the completion of the Contract.
Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms.
18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other.
18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1.
18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate.
18.5 Either party may terminate this Agreement immediately, if the other party:
(a) commits an irremediable breach; or
(b) is subject to a change of control or chooses to discontinue its business; or
(c) if the other party has a lack of funding or becomes or is deemed insolvent; or
(d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more.
18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you.
18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy.
18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data.
18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you.
18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due.
18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement.
18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.
Termination by ICANN (a) ICANN may, upon notice to Registry Operator, terminate this Agreement if: (i) Registry Operator fails to cure (A) any fundamental and material breach of Registry Operator’s representations and warranties set forth in Article 1 or covenants set forth in Article 2, or (B) any breach of Registry Operator’s payment obligations set forth in Article 6 of this Agreement, each within thirty (30) calendar days after ICANN gives Registry Operator notice of such breach, which notice will include with specificity the details of the alleged breach, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in fundamental and material breach of such covenant(s) or in breach of its payment obligations, and (iii) Registry Operator fails to comply with such determination and cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction.
(b) ICANN may, upon notice to Registry Operator, terminate this Agreement if Registry Operator fails to complete all testing and procedures (identified by ICANN in writing to Registry Operator prior to the date hereof) for delegation of the TLD into the root zone within twelve (12) months of the Effective Date. Registry Operator may request an extension for up to additional twelve (12) months for delegation if it can demonstrate, to ICANN’s reasonable satisfaction, that Registry Operator is working diligently and in good faith toward successfully completing the steps necessary for delegation of the TLD. Any fees paid by Registry Operator to ICANN prior to such termination date shall be retained by ICANN in full.
(c) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator fails to cure a material breach of Registry Operator’s obligations set forth in Section 2.12 of this Agreement within thirty (30) calendar days of delivery of notice of such breach by ICANN, or if the Continued Operations Instrument is not in effect for greater than sixty (60) consecutive calendar days at any time following the Effective Date, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in material breach of such covenant, and (iii) Registry Operator fails to cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction.
(d) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator makes an assignment for the benefit of creditors or similar act, (ii) attachment, garnishment or similar proceedings are commenced against Registry Operator, which proceedings are a material threat to Registry Operator’s ability to operate the registry for the TLD, and are not dismissed within sixty (60) calendar days of their commencement, (iii) a trustee, receiver, liquidator or equivalent is appointed in place of Registry Operator or maintains control over any of Registry Operator’s property, (iv) execution is levied upon any material property of Registry Operator, (v) proceedings are instituted by or against Registry Operator under any bankruptcy, insolvency, reorganization or other laws relating to the relief of debtors and such proceedings are not dismissed within sixty (60) calendar days of their commencement, or (vi) Registry Operator files for protection under the United States Bankruptcy Code, 11 U.S.C. Section 101, et seq., or a foreign equivalent or liquidates, dissolves or otherwise discontinues its operations or the operation of the TLD.
(e) ICANN may, upon thirty (30) calendar days’ notice to Registry Operator, terminate this Agreement pursuant to Section 2 of Specification 7 or Sections 2 and 3 of Specification 11, subject to Registry Operator’s right to challenge such termination as set forth in the applicable procedure described therein.
(f) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator knowingly employs any officer who is convicted of a misdemeanor related to financial activities or of any felony, or is judged by a court of competent jurisdiction to have committed fraud or breach of fiduciary duty, or is the subject of a judicial determination that ICANN reasonably deems as the substantive equivalent of any of the foregoing and such officer is not terminated within thirty (30) calendar days of Registry Operator’s knowledge of the foregoing, or (ii) any member of Registry Operator’s board of directors or similar governing body is convicted of a misdemeanor related to financial activities or of any felony, or is judged by a court of competent jurisdiction to have committed fraud or breach of fiduciary duty, or is the subject of a judicial determination that ICANN reasonably deems as the substantive equivalent of any of the foregoing and such member is not removed from Registry Operator’s board of directors or similar governing body within thirty (30) calendar days of Registry Operator’s knowledge of the foregoing.
(g) ICANN may, upon thirty (30) calendar days’ notice to Registry Operator, terminate this Agreement as specified in Section 7.5.
(h) [Applicable to intergovernmental organizations or governmental entities only.] ICANN may terminate this Agreement pursuant to Section 7.16.
Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.
