Third Party Maintenance Providers Sample Clauses

Third Party Maintenance Providers. Lessor and its Affiliates have contracts with third-party service providers with respect to the maintenance and inspection of certain Refinery Facilities and Shared Access Facilities which contracts have historically related in part to the Tank Farm Assets (the “Third Party Maintenance Contracts”). With respect to those Third Party Maintenance Contracts that have not been assigned to Lessee or its Affiliates or that Lessee or its Affiliates are not a party to, (i) Lessor or its Affiliates shall cause such third-party service providers to perform such services under such Third Party Maintenance Contracts as reasonably requested by Lessee or its Affiliates with respect to the Tank Farm Assets and (ii) Lessee and its Affiliates shall be solely responsible for any costs, fees or expenses or any Losses arising from such requests, and shall indemnify and hold harmless Lessor and its Affiliates therefor.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Third Party Maintenance Providers. Cisco reserves the right to subcontract services to a third party maintenance organization to provide Services to Customer.
Sample 1Sample 2
Third Party Maintenance Providers. The Developer shall have the right, from time to time, to select and hire a third party to perform the Maintenance Work, provided that the Developer shall remain responsible at all times for the performance of the Maintenance Work. If the Developer selects such third party to perform, supervise or coordinate the Maintenance Work (the “Property Manager”), such Property Manager must be a recognized professional commercial property management company. The Developer may hire companies affiliated with it to perform the Maintenance Work, but only if the rates charged by such companies are competitive with those of other companies furnishing similar service in the Minneapolis-St. Xxxx metropolitan area, it being agreed that this provision regarding affiliated companies shall be construed strictly against the Developer. Any contract with a Property Manager, and the amounts to be paid such Property Manager under such contract, shall be subject to the City’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such contracts shall be no longer than one (1) year in duration (but may provide for automatic renewal).
Sample 1

Related to Third Party Maintenance Providers

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

  • Property Maintenance Maintain all of its property that is necessary to or useful in the proper conduct of its business in good working condition, ordinary wear and tear excepted.

  • Equipment Maintenance If this Contract involves computer or telecommunications hardware or other mechanical or electrical Equipment maintenance (use of the word "Equipment" means all the foregoing) as a Deliverable, then, during the warranty period and during any period covered by annual maintenance, the Contractor will provide Equipment maintenance to keep the Equipment in or restore the Equipment to good working order. This maintenance will include preventative and remedial maintenance, installation of safety changes, and installation of engineering changes based upon the specific needs of the individual item of Equipment. This maintenance will also include the repair, replacement, or exchange deemed necessary to keep the Equipment in good working order. For purposes of this Contract, Equipment restored to good working condition means Equipment that performs in accordance with the manufacturer's published specifications. The Contractor will exert its best efforts to perform all fault isolation and problem determination attributed to the Equipment covered under this Contract. The following services are outside the scope of this Contract: 1. Repair and replacement work or increase in maintenance time as a result of damage or loss resulting from accident, casualty, neglect, misuse, or abuse if such is the State's fault (and beyond normal wear and tear), damage resulting from improper packing or failure to follow prescribed shipping instruction (If such is done by the State), failure of electrical power, air conditioning or humidity control, use of supplies not approved by the original manufacturer of the Equipment as describe or included in the Contractor's proposal, or causes other than ordinary use of Equipment. 2. All information necessary for the State to perform the maintenance, including but not limited to logic diagrams, maintenance manuals and system and unit schematics with all changes noted. 3. A listing of spare parts and their recommended replacement schedule that will enable the State to create a centralized inventory of spare parts.

  • Maintenance Program LESSEE's Maintenance Program

  • System Maintenance The Trust understands that USBFS will perform periodic maintenance to the System(s), which may cause temporary service interruptions. To the extent possible, USBFS shall notify the Trust of all planned outages and will perform any necessary maintenance during non-business hours.

  • Maintenance Outages If Seller reasonably determines that it is necessary to schedule a Maintenance Outage, Seller shall notify Buyer of the proposed Maintenance Outage at least five (5) days before the outage begins (or such shorter period to which Buyer may reasonably consent in light of then existing conditions). Upon such notice, the Parties shall plan the Maintenance Outage to mutually accommodate the reasonable requirements of Seller and the service obligations of Buyer; provided, however, that, unless Buyer otherwise consents, such consent not to be unreasonably withheld, no Maintenance Outage may be scheduled between the hour ending 0700 through the hour ending 2200, Monday through Saturday, during the time period commencing on May 15 and concluding on September 15. Notice of a proposed Maintenance Outage shall include the expected start date and time of the outage, the amount of Capacity of the Facility that will not be available, and the expected completion date and time of the outage. Seller shall give Buyer notice of the Maintenance Outage as soon as Seller determines that the Maintenance Outage is necessary. Buyer shall promptly respond to such notice and may request reasonable modifications in the schedule for the outage. Seller shall use all reasonable efforts to comply with any request to modify the schedule for a Maintenance Outage. Seller shall notify Buyer of any subsequent changes in Capacity available to Buyer or any changes in the Maintenance Outage completion date and time. As soon as practicable, any notifications given orally shall be confirmed in writing. Seller shall take all reasonable measures and exercise its best efforts in accordance with Prudent Electrical Practices to minimize the frequency and duration of Maintenance Outages.

  • Account Maintenance Trade Allocations Trade Reporting; (Futures) Daily Trade Checkout Daily Statement Reconciliation

  • Maintenance Scheduling The NTO shall schedule maintenance of its facilities designated as NTO Transmission Facilities Under ISO Operational Control and schedule any outages (other than forced transmission outages) of said transmission system facilities in accordance with outage schedules approved by the ISO. The NTO shall comply with maintenance schedules coordinated by the ISO, pursuant to this Agreement, for NTO Transmission Facilities Under ISO Operational Control. The NTO shall be responsible for providing notification of maintenance schedules to the ISO for NTO Transmission Facilities Requiring ISO Notification. The NTO shall provide notification of maintenance schedules to affected Transmission Owners for NTO Transmission Facilities Requiring ISO Notification and Local Area Transmission Facilities pursuant to Section 3.5.3 of the ISO Services Tariff.

  • Maintenance of Services A. Reseller will adopt and adhere to the standards contained in the applicable BellSouth Work Center Interface Agreement regarding maintenance and installation of service. B. Services resold under the Company’s Tariffs and facilities and equipment provided by the Company shall be maintained by the Company. C. Reseller or its end users may not rearrange, move, disconnect, remove or attempt to repair any facilities owned by the Company, other than by connection or disconnection to any interface means used, except with the written consent of the Company. D. Reseller accepts responsibility to notify the Company of situations that arise that may result in a service problem. E. Reseller will be the Company's single point of contact for all repair calls on behalf of Reseller’s end users. The parties agree to provide one another with toll-free contact numbers for such purposes. F. Reseller will contact the appropriate repair centers in accordance with procedures established by the Company. G. For all repair requests, Reseller accepts responsibility for adhering to the Company's prescreening guidelines prior to referring the trouble to the Company. H. The Company will xxxx Reseller for handling troubles that are found not to be in the Company's network pursuant to its standard time and material charges. The standard time and material charges will be no more than what BellSouth charges to its retail customers for the same services. I. The Company reserves the right to contact Reseller’s customers, if deemed necessary, for maintenance purposes.

  • Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!