Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Purchaser's Election to Delay Foreclosure Proceedings (a) The Purchaser shall be deemed to direct the Company to direct (to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement) the related Servicer that in the event that the Company does not receive written notice of the Purchaser's election pursuant to subsection (b) below within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01 (a) (ii) subject to extension as set forth in Section 2.02(b), the related Servicer may proceed with the Commencement of Foreclosure in respect of such Mortgage Loan in accordance with its normal foreclosure policies without further notice to the Purchaser. Any foreclosure that has been initiated may be discontinued (i) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the related Servicer) or (ii) if the related Servicer has reached the terms of a forbearance agreement with the borrower. In the latter case, the related Servicer may complete such forbearance agreement unless instructed otherwise by the Purchaser within two Business Days notification.
(b) In connection with any Mortgage Loan with respect to which a notice under Section 2.01(a)(ii) has been given to the Purchaser, the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to delay the Commencement of Foreclosure until such time as the Purchaser determines that the related Servicer may proceed with the Commencement of Foreclosure. Such election must be evidenced by written notice received within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01(a)(ii). Such 24 hour period shall be extended for no longer than an additional four Business Days after the receipt of the information if the Purchaser requests additional information related to such foreclosure; provided, however, that the Purchaser will have at least one Business Day to respond to any requested additional information. Any such additional information shall be provided only to the extent it (i) is not confidential in nature and (ii) is obtainable by the related Servicer from existing reports, certificates or statements or is otherwise readily accessible to its servicing personnel. The Purchaser agrees that it has no right to deal with the mortgagor during such period. However, if such servicing activities include acceptance of a deed-in-lieu of foreclosure or short payoff, the Purchaser will be notified and given two Business Days to respond.
(c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Purchaser shall obtain a Current Appraisal as soon as practicable, but in no event more than 15 business days thereafter, and shall provide the Company with a copy of such Current Appraisal.
(d) Within two Business Days of making any Election to Delay Foreclosure, the Purchaser shall remit by wire transfer to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to the sum of (i) 125% of the greater of the unpaid principal balance of the Mortgage Loan and the value shown in the Current Appraisal referred to in subsection (c) above (or, if such Current Appraisal has not yet been obtained, the Company's estimate thereof, in which case the required deposit under this subsection shall be adjusted upon obtaining such Current Appraisal), and (ii) three months' interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If any Election to Delay Foreclosure extends for a period in excess of three months (such excess period being referred to herein as the "Excess Period"), within two Business Days the Purchaser shall remit by wire transfer in advance to the Company for deposit in the Collateral Fund the amount of each additional month's interest, as calculated by the Company, equal to interest on the Mortgage Loan at the applicable Mortgage Interest Rate for the Excess Period. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit any of the above amounts relating to the Mortgage Loan within two Business Days of the Election to Delay Foreclosure or within two Business Days of the commencement of the Excess Period subject to Section 3.01.
(e) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Company may withdraw from the Collateral Fund from time to time amounts necessary to reimburse the related Servicer for all related Monthly Advances and Liquidation Expenses thereafter made by such Servicer in accordance with the Pooling and Servicing Agreement and the related Servicing Agreement. To the extent that the amount of any such Liquidation Expenses is determined by the Company based on estimated costs, and the actual costs are subsequently determined to be higher, the Company may withdraw the additional amount from the Collateral Fund. In the event that the Mortgage Loan is brought current by the mortgagor and the foreclosure action is discontinued, the amounts so withdrawn from the Collateral Fund shall be redeposited if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. Except as provided in the preceding sentence, amounts withdrawn from the Collateral Fund to cover Monthly Advances and Liquidation Expenses shall not be redeposited therein or otherwise reimbursed to the Purchaser. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this subsection) shall be released to the Purchaser.
(f) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than the delay in Commencement of Foreclosure as provided herein). If and when the Purchaser shall notify the Company that it believes that it is appropriate to do so, the related Servicer may proceed with the Commencement of Foreclosure. In any event, if the Mortgage Loan is not brought current by the mortgagor by the time the loan becomes 6 months delinquent, the Purchaser's election shall no longer be effective and at the Purchaser's option, either (i) the Purchaser shall purchase the Mortgage Loan from the related Trust Estate at a purchase price equal to the fair market value as shown on the Current Appraisal, to be paid by (x) applying any balance in the Collateral Fund to such to such purchase price, and (y) to the extent of any deficiency, by wire transfer of immediately available funds from the Purchaser to the Company for deposit in the related Certificate Account; or (ii) the related Servicer shall proceed with the Commencement of Foreclosure.
(g) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Delay Foreclosure and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (f) above, the Company shall calculate the amount, if any, by which the value shown on the Current Appraisal obtained under subsection (c) exceeds the actual sales price obtained for the related Mortgaged Property (net of Liquidation Expenses and accrued interest related to the extended foreclosure period), and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser.
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
