Common use of Time for Completion and Extensions Clause in Contracts

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. ‌ A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.order.‌

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall will diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s ’S work with the work of other contractors so that CONTRACTOR’s ’S work or the work of others shall will not be delayed or impaired. CONTRACTOR shall will be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s ’S fault or neglect, CONTRACTOR shall will notify the COUNTY in writing within twenty-four (24) 24 hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) 24 hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s ’S sole judgment, the findings of fact justify such an extension. CONTRACTOR shall will cooperate with the COUNTY’s ’S investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s ’S construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall will diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s ’S work with the work of other contractors so that CONTRACTOR’s ’S work or the work of others shall will not be delayed or impaired. CONTRACTOR shall will be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract agreement documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s ’S fault or neglect, CONTRACTOR shall will notify the COUNTY in writing within twenty-four (24) 24 hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) 24 hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract agreement time when, in the COUNTY’s ’S sole judgment, the findings of fact justify such an extension. CONTRACTOR shall will cooperate with the COUNTY’s ’S investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract agreement time may be granted only for those delays which impact CONTRACTOR’s ’S construction schedule. Extensions of contract agreement time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. 8.4.1 Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. 8.4.2 Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. 8.4.3 If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service project by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s work with the work of other contractors so that the CONTRACTOR’s work or the work of others shall not be delayed or impaired. The CONTRACTOR shall be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. C. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.order.‌

Time for Completion and Extensions. A. A written Purchase Order is required for the CONTRACTOR to schedule or begin work. Purchase orders shall will be issued for Project/Services to the CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written Email notice, along with a purchase order, is acceptable notice to proceed is required for the CONTRACTOR to schedule or begin work. . B. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s work with the work of other contractors CONTRACTORs so that the CONTRACTOR’s work or the work of others shall will not be delayed or impaired. The CONTRACTOR shall will be solely responsible for all construction means, methods, techniques, sequences sequences, and procedures, as well as coordination of all portions of the work under the contract documents. The time for completion requirements are contained in Section 4 above. B. C. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereofof the delay, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension.. Example ITB 24-405 C. D. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTORthe Contractor. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR Contractor to schedule or begin work. Email notice is acceptable. B. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s work with the work of other contractors so that the CONTRACTOR’s work or the work of others shall not be delayed or impaired. The CONTRACTOR shall be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. The time for completion requirements are contained in Article 3.2 above. B. C. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. C. D. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall may be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall may be issued for Project/Services to the CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. Email notice is acceptable. B. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with within ninety (90) days of the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impairedwritten notice to proceed. The CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under to complete the contract documentsProject/Service on time. B. C. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. C. D. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. A written Purchase Order is required for the CONTRACTOR to schedule or begin work. Purchase orders shall will be issued for Project/Services to the CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written Email notice, along with a purchase order, is acceptable notice to proceed is required for the CONTRACTOR to schedule or begin work. . B. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s work with the work of other contractors CONTRACTORs so that the CONTRACTOR’s work or the work of others shall will not be delayed or impaired. The CONTRACTOR shall will be solely responsible for all construction means, methods, techniques, sequences sequences, and procedures, as well as coordination of all portions of the work under the contract documents. The time for completion requirements are contained in Section 4 above. B. C. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereofof the delay, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension.. Example ITB 24-404 C. D. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. Email notice is acceptable. B. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. C. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. D. If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall will be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall will diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s ’S work with the work of other contractors so that CONTRACTOR’s ’S work or the work of others shall will not be delayed or impaired. CONTRACTOR shall will be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s ’S fault or neglect, CONTRACTOR shall will notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) 24 hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s ’S sole judgment, the findings of fact justify such an extension. CONTRACTOR shall will cooperate with the COUNTY’s ’S investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s ’S construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall will be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall will diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s ’S work with the work of other contractors so that CONTRACTOR’s ’S work or the work of others shall will not be delayed or impaired. CONTRACTOR shall will be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s ’S fault or neglect, CONTRACTOR shall will notify the COUNTY in writing within twenty-four (24) 24 hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) 24 hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s ’S sole judgment, the findings of fact justify such an extension. CONTRACTOR shall will cooperate with the COUNTY’s ’S investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s ’S construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service project by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s ’S work with the work of other contractors so that the CONTRACTOR’s ’S work or the work of others shall not be delayed or impaired. The CONTRACTOR shall be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s ’S fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four two (242) hours business days after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. C. If the CONTRACTOR complies with the twenty-four two (242) hour notice business days’notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s ’S sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s ’S investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s ’S construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service project by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s ’S work with the work of other contractors so that the CONTRACTOR’s ’S work or the work of others shall not be delayed or impaired. The CONTRACTOR shall be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s ’S fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. C. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s ’S sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s ’S investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s ’S construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.

Time for Completion and Extensions. A. Purchase orders shall will be issued for Project/Services to the CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice Notice to proceed Proceed is required for the CONTRACTOR to schedule or begin work. Email notice is acceptable. B. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s work with the work of other contractors so that the CONTRACTOR’s work or the work of others shall will not be delayed or impaired. The CONTRACTOR shall will be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. The time for completion requirements are contained in Article 3.2 above. B. C. Should the CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to the CONTRACTOR’s fault or neglect, the CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereofof the delay, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. C. D. If the CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall will ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. The CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact the CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.