Time for lodgement Sample Clauses

Open Split View

Download

Share

Cite

Time for lodgement. (a) Bids must be received by Synergy on or before the Closing of Bids or as otherwise directed by Synergy.

Sample 1Sample 2

Save

Copy

Related to Time for lodgement

• Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.

• Time for Acceptance Unless the Optionee shall evidence his/her acceptance of this Option by execution of this Agreement within ten (10) days after its delivery to him/her, the Option and this Agreement shall be null and void.

• Public Posting of Approved Users’ Research Use Statement The PI agrees that information about themselves and the approved research use will be posted publicly on the dbGaP website. The information includes the PI’s name and Requester, project name, Research Use Statement, and a Non-Technical Summary of the Research Use Statement. In addition, and if applicable, this information may include the Cloud Computing Use Statement and name of the CSP or PCS. Citations of publications resulting from the use of controlled-access datasets obtained through this DAR may also be posted on the dbGaP website.

• Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

• Procedure for Acceptance If Tenant wishes to exercise Tenant’s right of first refusal with respect to the space described in the First Refusal Notice, then within five (5) business days after delivery of the First Refusal Notice to Tenant (“Election Date”), Tenant shall deliver notice to Landlord of Tenant’s exercise of its right of first refusal with respect to the entire space described in the First Refusal Notice and on the First Refusal Economic Terms contained therein. Subject to the remaining provisions of this Section 1.4.2, if Tenant does not exercise its right of first refusal within the five (5) business day period (on all of the First Refusal Economic Terms), then Landlord shall be free to lease the space described in the First Refusal Notice to anyone to whom Landlord desires on any terms Landlord desires and Tenant’s right of first refusal with respect to the space identified in the First Refusal notice shall thereupon automatically terminate; provided, however, that if Landlord intends to enter into a lease upon First Refusal Economic Terms which are, in the aggregate, materially more favorable to a prospective tenant than those First Refusal Economic Terms proposed by Landlord in the First Refusal Notice to Tenant, then Landlord shall first deliver written notice to Tenant (“Second Chance Notice”) providing Tenant with the opportunity to lease the First Refusal Space on such more favorable First Refusal Economic Terms. For purposes hereof, First Refusal Economic Terms shall be materially more favorable to a third party if such First Refusal Economic Terms reflect a net effective rental rate (including any rent abatement and Tenant Improvement costs/allowance and any other economic concessions) less than ninety-five percent (95%) of the net effective rental rate for such First Refusal Space as those proposed by Landlord in the First Refusal Notice to Tenant. Tenant’s failure to elect to lease the First Refusal Space upon such more favorable First Refusal Economic Terms by written notice to Landlord within five (5) business days after Tenant’s receipt of such Second Chance Notice from Landlord shall be deemed to constitute Tenant’s election not to lease such space upon such more favorable First Refusal Economic Terms, in which case Landlord shall be entitled to lease such space to any third (3rd) party on terms not materially more favorable to the third (3rd) party than those set forth in the Second Chance Notice; provided, however, that for purposes of the Second Chance Notice, First Refusal Economic Terms shall be materially more favorable to a third party if such First Refusal Economic Terms reflect a net effective rental rate (including any rent abatement and Tenant Improvement costs/allowance and any other economic concessions) less than ninety-eight percent (98%) of the net effective rental rate for such First Refusal Space as those proposed by Landlord in the First Refusal Notice to Tenant. If Landlord does lease such First Refusal Space to a third (3rd) party tenant pursuant to the terms and conditions of this Section 1.4.2, Tenant shall have no further right to lease such First Refusal Space. If Landlord does not enter into a lease or leases all of the First Refusal Space identified by Landlord in such First Refusal Notice within three (3) months after the date Landlord first delivered such First Refusal Notice to Tenant, then Landlord shall submit to Tenant a new First Refusal Notice with respect to any such unleased First Refusal Space before Landlord may lease such space to another party, provided that no existing Superior Right holder wishes to lease such space in accordance with its Superior Rights in which event the foregoing procedures shall again apply following Tenant’s receipt of such new First Refusal Notice. Notwithstanding anything to the contrary contained herein, Tenant must elect to exercise its right of first refusal, if at all, with respect to all of the space comprising the First Refusal Space offered by Landlord to Tenant at any particular time, and Tenant may not elect to lease only a portion thereof or object to any of the First Refusal Economic Terms.

• New Application for Licensure Any time after the three-month period has lapsed from the Effective Date of this Agreement and Respondent has paid the Administrative Penalty set forth in Section III, Paragraph 1 of this Order, Respondent may apply for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement in any or all of the Participating States with the understanding that each State Mortgage Regulator reserves the rights to fully investigate such application for licensure or petition for reinstatement of an MLO Activity Endorsement and may either approve or deny such application or petition pursuant to the normal process for such licensing or endorsement investigations. No license application or petition described in this paragraph will be denied solely based on the facts, circumstances, or consensual resolution provided for in this Agreement. Respondent further agrees that Respondent must satisfy the Administrative Penalty provision prior to submitting an application for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement.

• Notification of Recall Notification of recall from layoff shall be sent by certified mail, return receipt requested, deliverable to addressee only, to the employee's last known address. The notice shall give the employee a minimum of ten (10) calendar days within which to respond after the notice of recall has been mailed. Employees who decline recall or who, in the absence of extenuating circumstances, fail to respond within the time set for return to work, shall be presumed to have resigned and their name shall be removed from the seniority and preferred eligibility list.

• Deadline for Submission of Bids 19.1 Bids must be received by the Purchaser at the address specified under ITB Clause 18.2 no later than the time and date specified in the Bid Data Sheet.

• COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.

• Usage for Voice Mail Message Service Rated Incollects (originated in BellSouth and from other companies) can also be on Optional Daily Usage File. Rated Incollects will be intermingled with BellSouth recorded rated and unrated usage. Rated Incollects will not be packed separately.