Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
NOTICE OF INDEMNIFICATION CLAIMS If the Town seeks indemnification pursuant to this Article 13.2, it shall notify Competitive Supplier of the existence of a claim, or potential claim as soon as practicable after learning of such claim, or potential claim, describing with reasonable particularity the circumstances giving rise to such claim. Upon written acknowledgment by the Competitive Supplier that it will assume the defense and indemnification of such claim, the Competitive Supplier may assert any defenses which are or would otherwise be available to the Town.
Third Party Indemnification The Company hereby acknowledges that Indemnitee has or may from time to time obtain certain rights to indemnification, advancement of expenses and/or insurance provided by one or more third parties (collectively, the “Third-Party Indemnitors”). The Company hereby agrees that it is the indemnitor of first resort (i.e., its obligations to Indemnitee are primary and any obligation of the Third-Party Indemnitors to advance expenses or to provide indemnification for the same expenses or liabilities incurred by Indemnitee are secondary), and that the Company will not assert that the Indemnitee must seek expense advancement or reimbursement, or indemnification, from any Third-Party Indemnitor before the Company must perform its expense advancement and reimbursement, and indemnification obligations, under this Agreement. No advancement or payment by the Third-Party Indemnitors on behalf of Indemnitee with respect to any claim for which Indemnitee has sought indemnification from the Company shall affect the foregoing. The Third-Party Indemnitors shall be subrogated to the extent of such advancement or payment to all of the rights of recovery which Indemnitee would have had against the Company if the Third-Party Indemnitors had not advanced or paid any amount to or on behalf of Indemnitee. If for any reason a court of competent jurisdiction determines that the Third-Party Indemnitors are not entitled to the subrogation rights described in the preceding sentence, the Third-Party Indemnitors shall have a right of contribution by the Company to the Third-Party Indemnitors with respect to any advance or payment by the Third-Party Indemnitors to or on behalf of the Indemnitee.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”): (a) breach by Licensee of any duty, covenant or agreement contained in this Agreement or a lawsuit, action, or claim brought by any third party that includes any allegation which, if proven true, would constitute a breach by Licensee of any duty, covenant or agreement contained in this Agreement; (b) the development, use, manufacture, promotion, sale, distribution or other disposition of any Products by Licensee, its Affiliates, assignees, vendors or other third parties, for personal injury, including death, or property damage arising from any of the foregoing. The indemnification obligation under Article 6.3 shall not apply to any contributory negligence or product liability of the Indemnified Party which may have occurred prior to the execution of this Agreement. Licensee will indemnify and hold harmless the Indemnified Parties from and against any Liabilities resulting from: (i) any product liability or other claim of any kind related to the use by a third party of a Product that was manufactured, sold, distributed or otherwise disposed by Licensee, its Affiliates, assignees, vendors or other third parties; (ii) clinical trials or studies conducted by or on behalf of Licensee relating to any Products, including, without limitation, any claim by or on behalf of a human subject of any such clinical trial or study, any claim arising from the procedures specified in any protocol used in any such clinical trial or study, any claim of deviation, authorized or unauthorized, from the protocols of any such clinical trial or study, any claim resulting from or arising out of the manufacture or quality control by a third party of any substance administered in any clinical trial or study; (iii) Licensee’s failure to comply with all prevailing laws, rules and regulations pertaining to the development, testing, manufacture, marketing and import or export of Products.
Landlord Indemnification With respect to only those Hazardous Substances present on, in or under the Industrial Center as of the date of this Lease (the “Existing Hazardous Substances”), Landlord agrees to indemnify, defend (with counsel reasonably acceptable to Tenant) and hold Tenant harmless from and against any and all claims, judgments, damages, penalties, fines, liabilities, losses, suits, administrative proceedings and costs (including, but not limited to, reasonable attorneys’ and consultant fees and court costs), arising at any time during or after the Term of this Lease, to the extent arising from (1) any of the Existing Hazardous Substances and/or (2) the removal, investigation, monitoring or remediation of any of the Existing Hazardous Substances; provided, however, Landlord shall not indemnify, defend or hold Tenant harmless to the extent (x) Tenant or any of the Tenant Entities contributes to or has contributed to the presence of such Existing Hazardous Substances or Tenant and/or any of the Tenant Entities exacerbates the conditions caused by such Existing Hazardous Substances, or (y) Tenant and/or any of the Tenant Entities allows or permits persons over which Tenant or any of the Tenant Entities has control and/or for which Tenant or any of the Tenant Entities are legally responsible for, to cause such Existing Hazardous Substances to be present in, on, under, through or about any portion of the Premises, the Building or the Industrial Center, or does not take all reasonably appropriate actions to prevent such persons over which Tenant or any of the Tenant Entities has control and/or for which Tenant or any of the Tenant Entities are legally responsible from causing the presence of Existing Hazardous Substances in, on, under, through or about any portion of the Premises, the Building or the Industrial Center. Landlord’s obligations under this Paragraph 6.8 shall survive the Expiration Date or earlier termination of this Lease.
Notice of Indemnification Claim Promptly after receipt by an indemnified party under Section 5.1 or Section 5.2 of notice of the commencement of any action (including any governmental action), such indemnified party will, if a claim in respect thereof is to be made against any indemnifying party under Section 5.1 or Section 5.2, deliver to the indemnifying party a written notice of the commencement thereof and the indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume the defense thereof with counsel mutually satisfactory to the indemnifying parties. An indemnified party (together with all other indemnified parties that may be represented without conflict by one counsel) shall have the right to retain one separate counsel, with the reasonably incurred fees and expenses to be paid by the indemnifying party, if representation of such indemnified party by the counsel retained by the indemnifying party would be inappropriate due to actual or potential differing interests between such indemnified party and any other party represented by such counsel in such proceeding. The failure to deliver written notice to the indemnifying party within a reasonable time of the commencement of any such action, if prejudicial to its ability to defend such action, shall relieve such indemnifying party, to the extent so prejudiced, of any liability to the indemnified party under this Section 5, but the omission to deliver written notice to the indemnifying party will not relieve it of any liability that it may have to any indemnified party otherwise than under this Section 5. No indemnifying party, in the defense of any such claim or litigation, shall, except with the consent of each indemnified party, consent to entry of any judgment or enter into any settlement which does not include as an unconditional term thereof the giving by the claimant or the plaintiff to such indemnified party of a release from all liability in respect to such claim or litigation.
Release Indemnification (a) In further consideration of the execution of this Amendment by the Administrative Agent and the Lenders, each Loan Party, individually and on behalf of its successors (including any trustees acting on behalf of such Loan Party and any debtor in possession with respect to such Loan Party), assigns, Subsidiaries and Affiliates (collectively, the “Releasors”), hereby forever releases each Agent and Xxxxxx and their respective successors, assigns, parents, Subsidiaries, Affiliates, officers, employees, directors, agents and attorneys (collectively, the “Releasees”) from any and all debts, claims, demands, liabilities, responsibilities, disputes, causes, damages, actions and causes of actions (whether at law or in equity) and obligations of every nature whatsoever, whether liquidated or unliquidated, whether known or unknown, whether matured or unmatured, whether fixed or contingent that such Releasor has, had or may have against the Releasees, or any of them, which arise from or relate to any actions which the Releasees, or any of them, have or may have taken or omitted to take in connection with the Credit Agreement or the other Loan Documents prior to the date hereof, including with respect to the Obligations, any Collateral, the Credit Agreement, any other Loan Document and any third party liable in whole or in part for the Obligations. This provision shall survive and continue in full force and effect whether or not each Loan Party shall satisfy all other provisions of this Amendment or the other Loan Documents, including payment in full of all Obligations. Each Releasor understands, acknowledges and agrees that the foregoing release set forth above may be pleaded as a full and complete defense and may be used as a basis for an injunction against any action, suit or other proceeding which may be instituted, prosecuted or attempted in breach of the provisions of such release. (b) Each Loan Party hereby acknowledges and agrees that such Loan Party’s obligations under this Amendment shall include an obligation to indemnify and hold the Releasees harmless with respect to any indemnified liabilities in any manner relating to or arising out of the negotiation, preparation, execution, delivery, performance, administration and enforcement of this Amendment to the extent required by Section 11.04(b) of the Credit Agreement.
