Unavoidable Delay; Extension of Time of Performance Sample Clauses

Unavoidable Delay; Extension of Time of Performance. (a) In addition to the specific provisions of this Agreement, performance by any party hereunder shall not be deemed to be in default where delays or defaults are due to war; act of terrorism; insurrection; strikes; lock-outs; riots; floods; earthquakes; fires; casualties; acts of God; acts of the public enemy; epidemics; quarantine restrictions; freight embargoes; lack of transportation; governmental restrictions or priority; litigation; unusually severe weather; inability to secure necessary labor, materials or tools; delays of any contractor, subcontractor or supplier; acts of another party; acts or the failure to act of any public or governmental agency or entity (except that acts or the failure to act of the City shall not excuse performance by the City); or any other causes beyond the control or without the fault of the party claiming an extension of time to perform. An extension of time for any such cause shall only be for the period of the enforced delay, which period shall commence to run from the time of the commencement of the cause. If, however, notice by the party claiming such extension is sent to the other parties more than thirty (30) days after the commencement of the cause, the period shall commence to run only thirty (30) days prior to the giving of such notice. Times of performance under this Agreement may also be extended in writing by the City and the Developer.
Sample 1
AutoNDA by SimpleDocs
Unavoidable Delay; Extension of Time of Performance. In addition to specific provisions of this Lease, performance by any Party hereunder shall not be deemed to be in default where delays or defaults are due to any Force Majeure Event. Performance by Tenant shall not be deemed in default where delays are defaults are due to delays in granting of governmental approvals contemplated by the Development Agreement or this Lease. An extension of time for any such cause shall be one day for each day during the continuance of any Force Majeure Event. Each of Landlord and Tenant shall inform the other of the occurrence of a Force Majeure Event where an extension of time is claimed. In addition to automatic extensions for Force Majeure Events, Landlord may extend time for performance for up to a total of sixty (60) days upon good faith showing by Tenant of the need for such extension. “Force Majeure Event” means any event which prohibits or materially interferes with, delays or alters the performance of the applicable duty under this Lease, including, but not limited to the following: strikes or lockouts; unanticipated shortages of material or labor (excluding those caused by lack of funds); acts of the public enemy; confiscation or seizure by any government or public authority; injunction, restraining order or other court order or decree, initiative or referendum action; wars or war-like action (whether actual and pending or expected, and whether de jure or de facto); blockades; insurrections; riots; civil disturbances; pandemic; and acts of God; but excluding delays caused by lack of funds. The provisions of this Section shall not apply to nor operate to excuse Tenant from the payment of Net Rent or any other payments to be made in accordance with the terms of this Lease.
Sample 1
Unavoidable Delay; Extension of Time of Performance. In addition to specific provisions of this Lease, performance by any party hereunder shall not be deemed to be in default where delays or defaults are due to war; terrorist attacks at home or abroad; insurrection; strikes; lock-outs; riots; floods; earthquakes; fires; casualties; acts of God; acts of the public enemy or terrorists; epidemics; quarantine restrictions; freight embargoes; lack of transportation; governmental restrictions or priority; unusually severe weather; inability (when either party is faultless) of any contractor, subcontractor or supplier; acts of the other party. An extension of time for any such cause shall only be for the period of enforced delay, which period shall commence to run from the time of the commencement of the cause. If, however, notice by the party claiming such extension is sent to the other parties more than 30 days after the commencement of the cause, the period shall commence to run only 30 days prior to the giving of such notice. Times of performance under this Lease may also be extended in writing by the parties hereto.
Sample 1
Unavoidable Delay; Extension of Time of Performance 
Sample 1

Related to Unavoidable Delay; Extension of Time of Performance

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Excuse of Performance Seller shall not be liable for delays in performance or for non-performance due to failure or interruption of computer or telecommunication systems, acts of God, war, riot, fire, terrorism, labor trouble, unavailability of materials or components, explosion, accident, compliance with governmental requests, laws, regulations, orders or actions, or other unforeseen circumstances or causes beyond Seller's reasonable control. In the event of such delay, the time for performance or delivery shall be extended by a period of time reasonably necessary to overcome the effect of the delay.

  • Time of Performance Time for performance of the Scope of Services under this Agreement shall begin with receipt of the Notice to Proceed and end no later than December 31, 2026. Consultant shall complete the tasks described in the Scope of Services, within this time or within such additional time as may be extended by the County.

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Suspension of Performance Notwithstanding any other provision hereof, if an Event of Default or a Potential Event of Default has occurred and is continuing, the Non-Defaulting Party, upon written notice to the Defaulting Party, has the right (i) to suspend performance under any or all Transactions and (ii) to the extent an Event of Default has occurred and is continuing, to exercise any remedy available at law or in equity, except as limited be Section 5.7.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Prevention of Performance The Custodian will not be responsible for any failure to perform any of its obligations (nor will it be responsible for any unavailability of funds credited to the Cash Account) if such performance is prevented, hindered or delayed by a Force Majeure Event, in such case its obligations will be suspended for so long as the Force Majeure Event continues. “Force Majeure Event” means any event due to any cause beyond the reasonable control of the Custodian, such as restrictions on convertibility or transferability, requisitions, involuntary transfers, unavailability of communications system, sabotage, fire, flood, explosion, acts of God, civil commotion, strikes or industrial action of any kind, riots, insurrection, war or acts of government.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!