BILLED COSTS Charges for the services cited in Section II will be billed or cost applied in accordance with the procedures established by the county, and recorded on the books of the cost center providing the service. Such charges will be based on the actual allowable costs, as defined by Uniform Guidance, incurred by the cost center responsible for providing the service. Any differences between the billed allowable costs and the actual allowable costs for a particular accounting period will be considered in a subsequent agreement.
Shared Costs (i) If the Parties elect to establish two-way Local Interconnection Trunks for reciprocal exchange of traffic, the cost of the two-way Local Interconnection Entrance Facility and DTT shall be shared among the Parties. CenturyLink will xxxx XXXX for the entire DTT and Local Interconnection Entrance Facility provided by CenturyLink at the rates in Table 1. CLEC will bill CenturyLink for CenturyLink’s portion of the same DTT and Local Interconnection Entrance Facility at the same recurring rates in Table 1 charged by CenturyLink based on the portion defined in (ii) below.
(ii) CenturyLink’s portion of the DTT and Local Interconnection Entrance Facility will be based on the factor determined by CenturyLink using the following to assign the minutes for which CenturyLink is responsible: • All Local Traffic MOU that CenturyLink originates and sends to CLEC. • All CenturyLink originated IntraLATA LEC Toll MOU that CenturyLink sends to CLEC. • All other minutes are CLEC’s responsibility for purposes of allocating the shared costs.
Estimated Costs The proposed GMP Change Order shall include separately identified dollar amounts, stated as fixed sums, for Actual Costs as estimated by the Design-Builder for the complete construction of the Project, which amount shall include the all Trade Contract and Subcontract Sums, costs of materials, and any Component Change Order Sums;
Third Party Costs Except to the extent expressly provided herein to the contrary, all third party costs incurred in connection with actions to be taken by the Company shall solely be the responsibility of the Company, including, but not limited to, all legal, auditing, accounting, underwriting, brokerage, investor communications, and listing, reporting and registration fees or other costs of the SEC, any state or local governments, any national securities exchange and the Financial Industry Regulatory Authority, Inc.
Direct Costs The Contractor shall separately identify each item of deleted and added work associated with the change or other condition giving rise to entitlement to an equitable adjustment, including increases or decreases to unchanged work impacted by the change. For each item of work so identified, the Contractor shall propose for itself and, if applicable, its first two tiers of subcontractors, the following direct costs:
(1) Material cost broken down by trade, supplier, material description, quantity of material units, and unit cost (including all manufacturing burden associated with material fabrication and cost of delivery to site, unless separately itemized);
(2) Labor cost broken down by trade, employer, occupation, quantity of labor hours, and burdened hourly labor rate, together with itemization of applied labor burdens (exclusive of employer’s overhead, profit, and any labor cost burdens carried in employer’s overhead rate);
(3) Cost of equipment required to perform the work, identified with material to be placed or operation to be performed;
(4) Cost of preparation and/or revision to shop drawings and other submittals with detail set forth in paragraphs (e)(1) and (e)(2) of this clause;
(5) Delivery costs, if not included in material unit costs;
(6) Time-related costs not separately identified as direct costs, and not included in the Contractor’s or subcontractors’ overhead rates, as specified in paragraph
Excess Costs If the Permitted Costs exceeds the Finish Allowance, then Tenant shall pay all such excess costs (“Excess Costs”), provided, however, Landlord will, prior to the commencement of construction of Tenant’s Improvements, advise Tenant of the sum of the Contract Sum and the Construction Management Fee (the “Cost Estimate”). Tenant shall have five (5) business days from and after the receipt of such advice within which to approve or disapprove the Contract Sum and Cost Estimate. If Tenant fails to approve same by the expiration of the fifth such business day, then Tenant shall be deemed to have approved the Proposed Contract Sum and Cost Estimate. If Tenant disapproves the Contract Sum and Cost Estimate within such five (5) business day period, then Tenant shall either reduce the scope of Tenant’s Improvements such that the Contract Sum and Construction Management Fee do not exceed the Finish Allowance or, at Tenant’s option, Landlord shall obtain two (2) additional bids, provided that each day beyond such five (5) business day period and until the rebid is accepted by Tenant shall constitute a Tenant Delay hereunder. The foregoing process shall continue until a Contract Sum and Cost Estimate are accepted or deemed accepted by Tenant. Landlord and Tenant must approve (or be deemed to have approved) the Contract Sum for the construction of Tenant’s Improvements in writing prior to the commencement of construction.
Third-Party Charges Customer may incur charges from third party service providers that are separate and apart from the amounts charged by Comcast. These may include, without limitation, charges resulting from accessing on-line services, calls to parties who charge for their telephone based services, purchasing or subscribing to other offerings via the Internet or interactive options on Public View Video, Video, or otherwise. Customer agrees that all such charges, including all applicable taxes, are Customer’s sole responsibility. In addition, Customer is solely responsible for protecting the security of credit card information provided to others in connection with such transactions.
Start-Up Costs The Government of Ontario will provide:
Default – Reprocurement Costs In case of Contract breach by Contractor, resulting in termination by the County, the County may procure the goods and/or services from other sources. If the cost for those goods and/or services is higher than under the terms of the existing Contract, Contractor will be responsible for paying the County the difference between the Contract cost and the price paid, and the County may deduct this cost from any unpaid balance due the Contractor. The price paid by the County shall be the prevailing market price at the time such purchase is made. This is in addition to any other remedies available under this Contract and under law.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
