JOB NOTIFICATION AND ENFORCEMENT 4.1 The Employer shall forward a job notification to the appropriate International Union Representative designated by the Union for the area involved and a copy for the Local Union(s) having territorial jurisdiction, immediately upon his knowledge of all work to be done by the Employer and all subcontractors under the terms and conditions of this Agreement. The Union will designate the Local Union(s) which will have territorial jurisdiction. The job notification form to be used is attached to this Agreement as Addendum A.
Construction and Enforcement This Agreement shall be construed in accordance with the laws of the State of Florida, without and application of the principles of conflicts of laws. If it becomes necessary for any party to institute legal action to enforce the terms and conditions of this Agreement, and such legal action results in a final judgment in favor of such party ("Prevailing Party"), then the party or parties against whom said final judgment is obtained shall reimburse the Prevailing Party for all direct, indirect or incidental expenses incurred, including, but not limited to, all attorney's fees, court costs and other expenses incurred throughout all negotiations, trials or appeals undertaken in order to enforce the Prevailing Party's rights hereunder. Any suit, action or proceeding with respect to this Agreement shall be brought in the state or federal courts located in St. Lucie County in the State of Florida. The parties hereto hereby accept the exclusive jurisdiction and venue of those courts for the purpose of any such suit, action or proceeding. The parties hereto hereby irrevocably waive, to the fullest extent permitted by law, any objection that any of them may now or hereafter have to the laying of venue of any suit, action or proceeding arising out of or relating to this Agreement or any judgment entered by any court in respect thereof brought in St. Lucie County, Florida, and hereby further irrevocably waive any claim that any suit, action or proceeding brought in St. Lucie County, Florida, has been brought in an inconvenient forum.
Compliance and Enforcement If Contractor willfully fails to comply with any of the provisions of the LBE Ordinance, the rules and regulations implementing the LBE Ordinance, or the provisions of this Agreement pertaining to LBE participation, Contractor shall be liable for liquidated damages in an amount equal to Contractor’s net profit on this Agreement, or 10% of the total amount of this Agreement, or $1,000, whichever is greatest. The Director of the City’s Human Rights Commission or any other public official authorized to enforce the LBE Ordinance (separately and collectively, the “Director of HRC”) may also impose other sanctions against Contractor authorized in the LBE Ordinance, including declaring the Contractor to be irresponsible and ineligible to contract with the City for a period of up to five years or revocation of the Contractor’s LBE certification. The Director of HRC will determine the sanctions to be imposed, including the amount of liquidated damages, after investigation pursuant to Administrative Code §14B.17. By entering into this Agreement, Contractor acknowledges and agrees that any liquidated damages assessed by the Director of the HRC shall be payable to City upon demand. Contractor further acknowledges and agrees that any liquidated damages assessed may be withheld from any monies due to Contractor on any contract with City. Contractor agrees to maintain records necessary for monitoring its compliance with the LBE Ordinance for a period of three years following termination or expiration of this Agreement, and shall make such records available for audit and inspection by the Director of HRC or the Controller upon request.
Monitoring and Enforcement We have the right to: Remove or refuse to post any User Contributions for any or no reason in our sole discretion. Take any action with respect to any User Contribution that we deem necessary or appropriate in our sole discretion, including if we believe that such User Contribution violates the Terms of Use, including the Content Standards, infringes any intellectual property right or other right of any person or entity, threatens the personal safety of users of the Website or the public, or could create liability for PeopleGrove or the University. Disclose your identity or other information about You to any third party who claims that material posted by You violates their rights, including their intellectual property rights or their right to privacy. Take appropriate legal action, including without limitation, referral to law enforcement, for any illegal or unauthorized use of the Website. Terminate or suspend your access to all or part of the Website for any or no reason, including without limitation, any violation of these Terms of Use. Without limiting the foregoing, we have the right to cooperate fully with any law enforcement authorities or court order requesting or directing us to disclose the identity or other information of anyone posting any materials on or through the Website. YOU WAIVE AND HOLD HARMLESS PEOPLEGROVE AND THE UNIVERSITY FROM ANY CLAIMS RESULTING FROM ANY ACTION TAKEN BY PEOPLEGROVE OR THE UNIVERSITY DURING, OR TAKEN AS A CONSEQUENCE OF, INVESTIGATIONS BY EITHER PEOPLEGROVE, THE UNIVERSITY OR LAW ENFORCEMENT AUTHORITIES. However, we cannot review all material before it is posted on the Website, and cannot ensure prompt removal of objectionable material after it has been posted. Accordingly, we assume no liability for any action or inaction regarding transmissions, communications, or content provided by any user or third party. We have no liability or responsibility to anyone for performance or nonperformance of the activities described in this section. CONTENT STANDARDS These content standards apply to any and all User Contributions and use of the Website. User Contributions must in their entirety comply with all applicable federal, state, local, and international laws and regulations. Without limiting the foregoing, User Contributions must not: Contain any material that is defamatory, obscene, indecent, abusive, offensive, harassing, violent, hateful, inflammatory, or otherwise objectionable. Promote sexually explicit or pornographic material, violence, or discrimination based on race, sex, religion, nationality, disability, sexual orientation, or age. Infringe any patent, trademark, trade secret, copyright, or other intellectual property or other rights of any other person. Violate the legal rights (including the rights of publicity and privacy) of others or contain any material that could give rise to any civil or criminal liability under applicable laws or regulations or that otherwise may be in conflict with these Terms of Use and our Privacy Policy. Be likely to deceive any person. Promote any illegal activity, or advocate, promote, or assist any unlawful act. Cause annoyance, inconvenience, or needless anxiety or be likely to upset, embarrass, alarm, or annoy any other person. Impersonate any person, or misrepresent your identity or affiliation with any person or organization. Involve commercial activities or sales, such as contests, sweepstakes, and other sales promotions, barter, or advertising. Give the impression that they emanate from or are endorsed by us or any other person or entity, if this is not the case. COPYRIGHT POLICY We respect the intellectual property rights of others. It is our policy to respond to any claim that User Contributions posted on the Website infringes on the copyright or other intellectual property rights of any person or entity. If you are a copyright owner, or authorized on behalf of one, and you believe that the copyrighted work has been copied in a way that constitutes copyright infringement, please submit your claim via email to xxxxxxx@xxxxxxxxxxx.xxx, with the subject line: "Copyright Infringement" and include in your claim a detailed description of the alleged Infringement as detailed below, under "DMCA Notice and Procedure for Copyright Infringement Claims." You may be held accountable for damages (including costs and attorneys' fees) for misrepresentation or bad-faith claims on the infringement of any of your User Contributions found on and/or through the Website.
Interpretation and Enforcement 1. The Parties shall take all appropriate measures, whether general or specific, to ensure fulfilment of the obligations arising out of this Agreement and shall refrain from any measures which would jeopardise attainment of the objectives of this Agreement.
AND ENFORCEMENT 59. If at any time the City desires to modify any portion of this Agreement because of changed conditions making performance impossible or impractical or for any other reason, it will promptly notify the Department in writing, setting forth the facts and circumstances thought to justify modification and the substance of the proposed modification. Until there is written Agreement by the Department to the proposed modification, the proposed modification will not take effect. These actions must receive the prior written approval of the Department, which approval will not be unreasonably withheld or delayed.
County of Orange Child Support Enforcement In order to comply with the child support enforcement requirements of the County of Orange, within ten (10) days of notification of selection of award of CONTRACT but prior to official award of CONTRACT, the selected CONTRACTOR agrees to furnish to the CONTRACT MANAGER, the Purchasing Agent, or the agency/department deputy purchasing agent:
Law Enforcement 24.1 Each Party may cooperate with law enforcement authorities and national security authorities to the full extent required or permitted by Applicable Law in matters related to Services provided by it under this Agreement, including, but not limited to, the production of records, the establishment of new lines or the installation of new services on an existing line in order to support law enforcement and/or national security operations, and, the installation of wiretaps, trap-and-trace facilities and equipment, and dialed number recording facilities and equipment.
Collaboration on Compliance and Enforcement A Competent Authority will notify the other Competent Authority when the first-mentioned Competent Authority has reason to believe that an error may have led to incorrect or incomplete information reporting or there is non-compliance by a Reporting Financial Institution with the applicable reporting requirements and due diligence procedures consistent with the Common Reporting Standard. The notified Competent Authority will take all appropriate measures available under its domestic law to address the errors or non-compliance described in the notice.
GOVERNING LAW AND ENFORCEMENT (a) The choice of English law as the governing law of the Finance Documents will be recognised and enforced in its jurisdiction of incorporation.
