Compliance and Enforcement. If Contractor willfully fails to comply with any of the provisions of the LBE Ordinance, the rules and regulations implementing the LBE Ordinance, or the provisions of this Agreement pertaining to LBE participation, Contractor shall be liable for liquidated damages in an amount equal to Contractor’s net profit on this Agreement, or 10% of the total amount of this Agreement, or $1,000, whichever is greatest. The Director of the City’s Human Rights Commission or any other public official authorized to enforce the LBE Ordinance (separately and collectively, the “Director of HRC”) may also impose other sanctions against Contractor authorized in the LBE Ordinance, including declaring the Contractor to be irresponsible and ineligible to contract with the City for a period of up to five years or revocation of the Contractor’s LBE certification. The Director of HRC will determine the sanctions to be imposed, including the amount of liquidated damages, after investigation pursuant to Administrative Code §14B.17. By entering into this Agreement, Contractor acknowledges and agrees that any liquidated damages assessed by the Director of the HRC shall be payable to City upon demand. Contractor further acknowledges and agrees that any liquidated damages assessed may be withheld from any monies due to Contractor on any contract with City. Contractor agrees to maintain records necessary for monitoring its compliance with the LBE Ordinance for a period of three years following termination or expiration of this Agreement, and shall make such records available for audit and inspection by the Director of HRC or the Controller upon request.
Compliance and Enforcement a. The Contractor shall be subject to the COMPLIANCE AND ENFORCEMENT section of the M/WBE Program Policy and Administrative Procedures and Contract Provisions. If upon approval, the Contractor acknowledges and accepts that any failure to comply with any material term or condition of an approved compliance plan or applicable provision of the M/WBE Program Policy and Administrative Procedures, and Contract Provisions, including failure to satisfactorily address the project goal, maintain participation commitments or otherwise comply with any applicable requirements.
Compliance and Enforcement. 1. These provisions address the additional contractual remedies available to the Airport Board as a result of the Contractor’s failure to comply with the obligations set forth in the M/WBE Program Policy and Administrative Procedures. The contractual remedies set forth are also applicable to the Contractor’s failure to comply with the Program requirements, as well as any remedies available at law or in equity. These remedies are not intended to apply to the Contractor’s failure to comply with other obligations under the Contract unrelated to the Program requirements or preclude Airport Board’s recovery of its actual damages for such unrelated breaches.
Compliance and Enforcement. 1. These compliance and enforcement provisions address the additional contractual remedies available to Board as a result of Concessionaire’s failure, if any, to comply with the obligations set forth in the ACDBE Program requirements. The contractual remedies set forth in the ACDBE Program are also applicable to any failure to comply with the Program requirements, as well as any remedies available at law or in equity. These remedies are not intended to apply to any failure by Concessionaire to comply with other obligations under this Agreement unrelated to the Program requirements or preclude Board’s recovery of its actual damages for such unrelated breaches.
Compliance and Enforcement. Nutrition
Compliance and Enforcement a) The plan commission may waive or modify any design requirement contained in this section to allow alternative or innovative practices that implement the intent of the original design requirement and provide equivalent public benefits without significant adverse impacts on nearby properties.
Compliance and Enforcement. Contractor is subject to the compliance, enforcement and civil monetary penalties provisions at 45 C.F.R., Part 160, Subparts C and D.
Compliance and Enforcement. Section 26.109 Information, Confidentiality, Cooperation and Intimidation or Retaliation TxDOT will not release information that may be reasonably construed as confidential business information to any third party without the written consent of the firm that submitted the information. This includes applications for DBE Certification and supporting documentation. TxDOT will keep the identity of complainants confidential at their election, however complainants will be advised that in some circumstances, failure to waive the privilege will result in the closure of the investigation or proceeding or hearing. Federal Aviation Administration (FAA) follows the procedures of 14 CFR part 16 with respect to confidentiality of information and complaints. All participants in the Department’s DBE Program (including but not limited to, recipients, DBE firms and applicants for DBE certification, complainants and appellants and contractors using DBE firms to meet contract goals) are required to cooperate fully and promptly with DOT and recipient compliance reviews, certification reviews, investigation and other request for information. Failure to do so shall be a ground for appropriate action against the party involved. If you are a recipient, contractor, or any other participant in the program you must not intimidate, threaten, coerce, or discriminate against any individual or firm for the purpose of interfering with any right or privilege secured by this part or because the individual or firm has made a complaint, testified, assisted, or participated in any manner in an investigation, proceeding, or hearing under this part. If you violate this prohibition, you are in noncompliance with this part. Records must be retained for a period of 3 years following completion of the contract work, and shall be available at reasonable times and places for inspection by authorized representatives of the Department or the DOT. Provide copies of subcontracts or agreements and other documentation upon request. ATTACHMENTS Attachment 1 DBE Regulations: 49 CFR Part 26 Attachment 2 DBE Special Provision 000461 Attachment 3 OrganizationaI Chart Attachment 4 Measurement and Payment Special Provision 009-007 Attachment 5 TUCP DBE directory example and website address to the directory Attachment 6 DBE Goal Methodology Attachment 7 DBE Bidder Certification Attachment 8 DBE Joint Check Approval Form Attachment 9 TUCP SOP Attachment 10 TUCP MOA ATTACHMENT 2 TO EXHIBIT K DBE PROVISIONS SPECIAL PRO...
Compliance and Enforcement. 21.1 Where a project proceeds under an EA Certificate, the EAO will assign a primary contact for Lake Xxxxxx in relation to the project, and who is responsible for:
Compliance and Enforcement. The power of WECC to enforce Member obligations other than compliance with Reliability Standards and other obligations arising under 18 C.F.R. Part 39 and applicable Canadian and Mexican regulatory requirements is limited to suspension or termination of membership as set forth in this Section; provided, however, that: 1) nothing in this Section will limit the power of Members to agree to additional enforcement provisions in separate contracts (such as contracts pursuant to the Reliability Management System); 2) nothing in this Section will limit the power of WECC to propose solutions regarding Market Interface issues to any Applicable Regulatory Authority as described in Section 2.1.10; and 3) nothing in this Section will limit WECC’s delegated authority under Section 215 of the Federal Power Act and 18 C.F.R. Part 39 and applicable Canadian and Mexican regulatory requirements to enforce reliability standards and perform other delegated or contractual functions within the Western Interconnection. The Board may suspend or, to the extent consistent with applicable law, terminate the membership of any Member for a material failure to meet any obligation of membership set forth in these Bylaws, including, but not limited to: 1) non-payment of dues sixty (60) days after the dues become delinquent; 2) intentionally or repeatedly violating any WECC Bylaw; 3) materially breaching or intentionally violating any FERC order or arbitration decision issued pursuant to these Bylaws; 4) willfully obstructing any lawful purpose or activity of WECC; or 5) remaining inactive as described in Section 5.9. The Board will give the affected Member not less than twenty-one (21) days prior written notice of any proposed suspension or termination, which will include the specific basis for the proposed action and, if applicable, instructions on curing the problem. Prior to terminating a membership, the Board will consider any information provided by the Member in response to the notice described herein.
