Use of Proceeds and Specific Tax Covenants Sample Clauses

Use of Proceeds and Specific Tax Covenants. The Series 2022 Bonds are being issued by the Authority in compliance with the conditions necessary for interest income on the Series 2022 Bonds to be excluded from gross income for federal income tax purposes pursuant to the provisions of Section 103(a) of the Code relating to obligations of the State or political subdivisions thereof. It is the intention of the Authority and the County that the interest on the Series 2022 Bonds be and remain excludable from gross income for federal income tax purposes, and, to that end, the Authority and the County hereby covenant with the Bondholders as follows: (a) That they will not take any action, or fail to take any action, if any such action or failure to take action would adversely affect the tax exempt status of interest on the Series 2022 Bonds under Section 103 of the Code. (b) That they will not directly or indirectly use or permit the use of any of the proceeds of the Series 2022 Bonds or take or omit to take any action in a way that would cause the Series 2022 Bonds to be (i) “private activity bonds” within the meaning of Section 141 of the Code or (ii) obligations which are “federally guaranteed” within the meaning of Section 149(b) of the Code. (c) That they will not directly or indirectly use or permit the use of any proceeds of the Series 2022 Bonds or any other funds of the Authority or the County or take or omit to take any action that would cause the Series 2022 Bonds to be “arbitrage bonds” within the meaning of Section 148 of the Code. To that end, the Authority and the County will comply with all requirements of Section 148 of the Code and any regulations promulgated thereunder to the extent applicable to the Authority or the County. In the event that at any time the Authority or the County is of the opinion that for purposes of this Section it is necessary to restrict or limit the yield on the investment of any moneys held under the Bond Resolution, the Authority and the County shall take such action as may be necessary to effect the same.
Sample 1
AutoNDA by SimpleDocs

Related to Use of Proceeds and Specific Tax Covenants

  • Use of Project Issuer does hereby covenant and agree that it will not take any action during the term of this Agreement, other than pursuant to Article IX of this Agreement or Article IX of the Indenture, to interfere with Company's ownership of the Project or to prevent Company from having possession, custody, use and enjoyment of the Project.

  • Compliance with Laws; Use of Proceeds Each Loan Party shall, and shall cause each of its Subsidiaries to, comply with all applicable Laws, including all Environmental Laws, in all respects; provided that it shall not be deemed to be a violation of this Section 8.1.7 if any failure to comply with any Law would not result in fines, penalties, remediation costs, other similar liabilities or injunctive relief which in the aggregate would constitute a Material Adverse Change. The Loan Parties will use the Letters of Credit and the proceeds of the Loans only in accordance with Section 2.8 [Use of Proceeds] and as permitted by applicable Law.

  • Use of Proceeds; Margin Regulations The Company will apply the proceeds of the sale of the Bonds to repay existing indebtedness and for general corporate purposes and in compliance with all laws referenced in Section 5.16. No part of the proceeds from the sale of the Bonds hereunder will be used, directly or indirectly, for the purpose of buying or carrying any margin stock within the meaning of Regulation U of the Board of Governors of the Federal Reserve System (12 CFR 221), or for the purpose of buying or carrying or trading in any securities under such circumstances as to involve the Company in a violation of Regulation X of said Board (12 CFR 224) or to involve any broker or dealer in a violation of Regulation T of said Board (12 CFR 220). Margin stock does not constitute more than 2% of the value of the consolidated assets of the Company and its Subsidiaries and the Company does not have any present intention that margin stock will constitute more than 2% of the value of such assets. As used in this Section, the terms “margin stock” and “purpose of buying or carrying” shall have the meanings assigned to them in said Regulation U.

  • Use of Proceeds and Letters of Credit The proceeds of the Loans will be used only (i) to refinance amounts outstanding under the Existing Credit Agreement; (ii) to pay the fees, expenses and other transaction costs of the Transactions contemplated hereby, (iii) to fund working capital needs, (iv) to fund acquisitions permitted hereunder, together with related expenses, and engage in other transactions permitted hereby, (v) to provide funding in connection with capital expenditures, (vi) to make Restricted Payments permitted hereunder and (vii) for general corporate purposes of the Borrower and its Subsidiaries. No part of the proceeds of any Loan will be used, whether directly or indirectly, for any purpose that entails a violation of any of the regulations of the Board, including Regulations T, U and X. Letters of Credit will be issued only to support the working capital needs and general corporate obligations of the Borrower and its Subsidiaries relating to their respective lines of business. The Borrower will not request any Borrowing or Letter of Credit, and the Borrower shall not use, and shall procure that its Subsidiaries and its or their respective directors, officers, employees and agents shall not use, the proceeds of any Borrowing or Letter of Credit (A) in furtherance of an offer, payment, promise to pay, or authorization of the payment or giving of money, or anything else of value, to any Person in violation of any Anti-Corruption Laws, (B) for the purpose of funding, financing or facilitating any activities, business or transaction of or with any Sanctioned Person, or in any Sanctioned Country, to the extent such activities, businesses or transaction would be prohibited by Sanctions if conducted by a corporation incorporated in the United States, or (C) in any manner that would result in the violation of any Sanctions applicable to any party hereto.

  • Use of Proceeds The Company will use the net proceeds received by it from the sale of the Securities in the manner specified in the Prospectus under “Use of Proceeds.”

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Use of Proceeds of the Loan Section 3.01. The Borrower shall cause the proceeds of the Loan to be applied to the financing of expenditures on the Project in accordance with the provisions of this Loan Agreement. Section 3.02. The proceeds of the Loan shall be allocated and withdrawn in accordance with the provisions of Schedule 3 to this Loan Agreement, as such Schedule may be amended from time to time by agreement between the Borrower and ADB. Section 3.03. Except as ADB may otherwise agree, the Borrower shall procure, or cause to be procured, the items of expenditure to be financed out of the proceeds of the Loan in accordance with the provisions of Schedule 4 to this Loan Agreement. Section 3.04. Except as ADB may otherwise agree, the Borrower shall cause all items of expenditure financed out of the proceeds of the Loan to be used exclusively in the carrying out of the Project. Section 3.05. Withdrawals from the Loan Account in respect of Goods, Works, and Consulting Services shall be made only on account of expenditures relating to: (a) Goods which are produced in and supplied from and Works and Consulting Services which are supplied from such member countries of ADB as shall have been specified by ADB from time to time as eligible sources for procurement; and (b) Goods, Works, and Consulting Services which meet such other eligibility requirements as shall have been specified by ADB from time to time. Section 3.06. The Loan Closing Date for the purposes of Section 8.02 of the Loan Regulations shall be 30 June 2019 or such other date as may from time to time be agreed between the Borrower and ADB.

  • Application of Proceeds of Sale The proceeds of any sale of Collateral pursuant to Section 6, as well as any Collateral consisting of cash, shall be applied by the Collateral Agent as follows: FIRST, to the payment of all costs and expenses incurred by the Collateral Agent in connection with such sale or otherwise in connection with this Agreement, any other Loan Document or any of the Obligations, including all court costs and the reasonable fees and expenses of its agents and legal counsel, the repayment of all advances made by the Collateral Agent hereunder or under any other Loan Document on behalf of any Pledgor and any other costs or expenses incurred in connection with the exercise of any right or remedy hereunder or under any other Loan Document; SECOND, to the payment in full of the Obligations (the amounts so applied to be distributed among the Secured Parties pro rata in accordance with the amounts of the Obligations owed to them on the date of any such distribution); and THIRD, to the Pledgors, their successors or assigns, or as a court of competent jurisdiction may otherwise direct. The Collateral Agent shall have absolute discretion as to the time of application of any such proceeds, moneys or balances in accordance with this Agreement. Upon any sale of the Collateral by the Collateral Agent (including pursuant to a power of sale granted by statute or under a judicial proceeding), the receipt of the purchase money by the Collateral Agent or of the officer making the sale shall be a sufficient discharge to the purchaser or purchasers of the Collateral so sold and such purchaser or purchasers shall not be obligated to see to the application of any part of the purchase money paid over to the Collateral Agent or such officer or be answerable in any way for the misapplication thereof.

  • Contracts Concerning Use of Project The Recipient agrees that during the Agreement Term it will not contract with any Private Person for use of the Project or any portion thereof or the facility or facilities of which the Project is a part for any Private Business Use unless all of the conditions of subparagraph F.3.a., subparagraph F.3.b. or subparagraph F.3.c. are met: a. If the compensation of the Private Person is based entirely on a periodic, fixed fee that contains no incentive adjustments, all of the following conditions must be met: (A) no amount of compensation is based on a share of the net profits; (B) the compensation is reasonable; (C) the term of the contract does not exceed five (5) years (including any renewal option periods provided for in the contract);

  • Maintenance of Properties and Leases Each Loan Party shall, and shall cause each of its Subsidiaries to, maintain in good repair, working order and condition (ordinary wear and tear excepted) in accordance with the general practice of other businesses of similar character and size, all of those properties useful or necessary to its business, and from time to time, such Loan Party will make or cause to be made all appropriate repairs, renewals or replacements thereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!