Utility Adjustment Risk Sample Clauses

Utility Adjustment Risk. 21 5.10.4.1 Except with respect to Developer’s rights to claim a Relief 22 Event for Utility Company Delays pursuant to Section 14.4.4, for Inaccurate Utility 23 Information pursuant to Section 14.4.5, or for ADOT-Caused Delay respecting ADOT 24 Utility Adjustments, Developer shall not be entitled to submit a Claim for Extra Work 25 Costs, Delay Costs, Completion Deadline adjustment or other relief related to the Utility 26 Adjustment Work, inaccuracy of the Utility Information or Utilities located within or 27 outside the Project ROW or otherwise impacted by, or having an impact on, the Project 28 or the Work.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Utility Adjustment Risk. 37 5.10.4.1 Except with respect to Developer’s rights to claim a Relief 38 Event for Utility Company Delays pursuant to Section 14.4.4, for Inaccurate Utility 39 Information pursuant to Section 14.4.5, or for ADOT-Caused Delay respecting ADOT 40 Utility Adjustments, Developer shall not be entitled to submit a Claim for Extra Work 1 Costs, Delay Costs, Completion Deadline adjustment or other relief related to the Utility 2 Adjustment Work, inaccuracy of the Utility Information or Utilities located within or 3 outside the Project ROW or otherwise impacted by, or having an impact on, the Project 4 or the Work. 6 payments out of the D&C Price) the Utility Adjustment Work itself, if permitted by the 7 Utility Company (except that any assistance provided by any Developer-Related Entity 8 to the Utility Company in acquiring Replacement Utility Property Interests shall be 9 provided outside of the Work); or (b) reimburse (out of the D&C Price or otherwise) the 10 Utility Company for its Utility Adjustment Work within the time and in the manner 11 required by the applicable Utility Agreement. However, Developer has no obligation to 12 reimburse a Utility Company for Utility Adjustment costs for any Service Line 13 Adjustment for which the affected property owner has been compensated in connection 14 with Project ROW acquisition. Developer is solely responsible for collecting directly 15 from the Utility Company any reimbursement due to Developer for Betterment costs or 16 other costs incurred by Developer for which the Utility Company is responsible under 17 applicable Law. 18 5.10.4.3 For each Utility Adjustment, the eligibility of Utility Company 19 costs (both indirect and direct) for reimbursement by Developer, as well as the 20 determination of any Betterment or other costs due to Developer, shall be established in 21 accordance with applicable Law and the applicable Utility Agreement(s).
Sample 1Sample 2
Utility Adjustment Risk. 5.2.5.1 Except with respect to DBT’s rights to claim a Relief Event for Unknown Utilities, DBT shall not be entitled to an increase in the Contract Price, a Completion Deadline adjustment or any other Claim or Relief Event related to the Utility Adjustment Work, inaccuracy of the Utility Information or Utilities located within or outside the Schematic ROW or otherwise impacted by, or having an impact on, the Project or the Work.
Sample 1Sample 2
Utility Adjustment Risk. 2 5.4.4.1 Except with respect to Xxxxxxxxx’s rights to claim a Relief 3 Event for Utility Company Delays pursuant to Section 13.4.3 or for Inaccurate Utility 4 Information pursuant to Section 13.4.4, Developer shall not be entitled to an increase in 5 the Contract Price, a Completion Deadline adjustment or any other Claim or Relief Event 6 related to the Utility Adjustment Work, inaccuracy of the Utility Information or Utilities 7 located within or outside the Project ROW or otherwise impacted by, or having an impact 8 on, the Project or the Work.
Sample 1
Utility Adjustment Risk. 18 5.10.4.1 Developer’s right to Claims in connection with the Utility 19 Adjustment Work is limited to the relief this Agreement provides for Utility Company 20 Delays and Inaccurate Utility Information, and subject to further limitations pursuant to 21 Sections 14.4.4 and 14.4.5.
Sample 1
Utility Adjustment Risk. 28 5.10.4.1 Developer’s right to Claims in connection with the Utility 29 Adjustment Work is limited to the relief this Agreement provides for Utility Company 30 Delays and Inaccurate Utility Information, and subject to further limitations pursuant to 31 Sections 14.4.4 and 14.4.5. 32 5.10.4.2 Developer shall: (a) perform at its own cost (subject to 33 payments out of the D&C Price) the Utility Adjustment Work itself, if permitted by the 34 Utility Company (except that any assistance provided by any Developer-Related Entity 35 to the Utility Company in acquiring Replacement Utility Property Interests shall be 36 provided outside of the Work); or (b) reimburse (out of the D&C Price or otherwise) the 37 Utility Company for its Utility Adjustment Work within the time and in the manner 38 required by the applicable Utility Agreement. However, Developer has no obligation to 39 reimburse a Utility Company for Utility Adjustment costs for any Service Line 40 Adjustment for which the affected property owner has been compensated in connection 1 with Project ROW acquisition. Developer is solely responsible for collecting directly 2 from the Utility Company any reimbursement due to Developer for Betterment costs or 3 other costs incurred by Developer for which the Utility Company is responsible under 4 applicable Law.
Sample 1
Utility Adjustment Risk. 37 5.10.4.1 Except with respect to Developer’s right to Claims in 38 connection with the Utility Adjustment Work is limitedrights to the relief this Agreement 39 providesclaim a Relief Event for Utility Company Delays andpursuant to Section 14.4.4, 40 for Inaccurate Utility Information, and subject to further limitations pursuant to 1 Sections 14.4.4 andSection 14.4.5. , or for ADOT-Caused Delay respecting ADOT 2 Utility Adjustments, Developer shall not be entitled to submit a Claim for Extra Work 3 Costs, Delay Costs, Completion Deadline adjustment or other relief related to the Utility 4 Adjustment Work, inaccuracy of the Utility Information or Utilities located within or 5 outside the Project ROW or otherwise impacted by, or having an impact on, the Project 6 or the Work.
Sample 1
AutoNDA by SimpleDocs
Utility Adjustment Risk. 7 5.10.4.1 Developer’s right to Claims in connection with the Utility 8 Adjustment Work is limited to the relief this Agreement provides for Utility Company 9 Delays and Inaccurate Utility Information, and subject to further limitations pursuant to 10 Sections 14.4.4 and 14.4.5.
Sample 1

Related to Utility Adjustment Risk

  • EQUITY ADJUSTMENTS The parties subscribe to the principle of equal pay for work of equal value. The parties will continue to move towards the mutual goal of the Community Social Services Sector achieving the objectives set out in Sections A(1), (2) and (3) above, as follows:

  • Workforce Adjustment (a) The Parties recognize that workforce adjustment may be necessary due to the elimination of positions resulting from a reduction in the amount of work required to be done by the Commission, reorganization or program termination.

  • Wage Adjustment Notwithstanding any provision in this Agreement on the contrary, the wages of employees shall be reduced by the amount of employee contributions made by the employer pursuant to the provisions hereof.

  • Supervisory Differential Adjustment 99. The Appointing Officer may adjust the compensation of a supervisory employee whose schedule of compensation is set herein subject to the following conditions:

  • Contingent Price Adjustment It is the policy of the State of Oregon that unprocessed timber shall not be exported from lands owned or managed by the STATE or any of its political subdivisions or agencies, in accordance with the terms of current federal law and the Constitution and the laws of the State of Oregon. PURCHASER specifically agrees that Section 1 is a material term of this contract and is part of the consideration offered to STATE in return for STATE's performance. In the event that any federal law or state constitutional provision or law or any provision of this contract concerning export of unprocessed timber is declared invalid by any court or administrative tribunal, PURCHASER agrees to pay to STATE a contingent price in the amount of the difference between the purchase price set forth in this section and the price obtained by PURCHASER for the exported unprocessed timber. The default provisions of OAR 629-032-0000 through 629-032-0070 shall not apply to exported unprocessed timber. In the event that timber made available under this contract is exported in violation of this contract, PURCHASER shall be in material breach of the contract. STATE shall be entitled to cease performance of the contract and recover, in addition to the adjusted price set out above, a further sum estimated to compensate for administrative expense and the economic impact of the violation upon the State and its citizens. In no case shall this additional amount be less than $10,000 per incident.

  • Workplace adjustment An employer wishing to employ a person under the provisions of this clause shall take reasonable steps to make changes in the workplace to enhance the employee’s capacity to do the job. Changes may involve re-design of job duties, working time arrangements and work organisation in consultation with other employees in the area.

  • ECONOMIC PRICE ADJUSTMENT is the adjustment to the Aircraft Basic Price (Base Airframe, Engine and Special Features) as calculated pursuant to Exhibit D.

  • Contract Price Adjustment The basis upon which the Contract Price shall be adjusted is as set out in paragraph 9.2 of Schedule IVB.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!