Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Continuing Performance Each party is required to continue to perform its obligations under this contract pending final resolution of any dispute arising out of or relating to this contract, unless to do so would be impossible or impracticable under the circumstances.
Termination for Non-Performance Should a party to this Agreement fail to materially perform in accordance with the terms and conditions of this Agreement, this Agreement may be terminated by the performing party if the performing party first provides written notice to the non-performing party which notice shall specify the non-performance, provide both a demand to cure the non-performance and reasonable time to cure the non-performance, and state a date upon which the Agreement shall be terminated if there is a failure to timely cure the non- performance. For purpose of this Section 4.4, “reasonable time” shall be not less than five (5) business days. In the event of a failure to timely cure a non- performance and upon the date of the resulting termination for non-performance, the Contractor shall prepare a final accounting and final invoice of charges for all performed but unpaid Services and authorized reimbursable expenses. Such final accounting and final invoice shall be delivered to the Town within fifteen (15) days of the date of termination; thereafter, no other invoice, xxxx, or other form of statement of charges owing to the Contractor shall be submitted to or accepted by the Town. Provided that notice of non-performance is provided in accordance with this Section 4.4, nothing in this Section 4.4 shall prevent, preclude, or limit any claim or action for default or breach of contract resulting from non-performance by a Party.
Acceptance/Performance Test 4.7.1 Prior to synchronization of the Power Project, the SPD shall be required to get the Project certified for the requisite acceptance/performance test as may be laid down by Central Electricity Authority or an agency identified by the central government to carry out testing and certification for the solar power projects.
Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).
TIMELY PERFORMANCE (a) SELLER's timely performance is a critical element of this Contract.
POOR PERFORMANCE Authorized Users should notify NYSPro Customer Services promptly if the Contractor fails to meet the requirements of the contracts resulting from this solicitation. Performance which does not comply with requirements or is otherwise unsatisfactory to the Authorized User should also be reported to Customer Services: Office of General Services Tel: 000-000-0000 New York State Procurement Fax: 000-000-0000 Customer Services Email: xxxxxxxx.xxxxxxxx@xxx.xx.xxx 00xx Xxxxx Xxxxxxx Xxxxx Xxxxxx Xxxxx Xxxxx Xxxxxx, XX 00000
Monitoring of Contract Performance The Contractor shall comply with the monitoring arrangements set out in the Monitoring Schedule including, but not limited to, providing such data and information as the Contractor may be required to produce under the Contract.
F2 Monitoring of Contract Performance F2.1 The Contractor shall immediately inform the Authority if any aspect of the Contract is not being or is unable to be performed, the reasons for non-performance, any corrective action and the date by which that action will be completed.
Rating of Overall Educator Performance The Educator’s overall performance rating is based on the Evaluator’s professional judgment and examination of evidence of the Educator’s performance against the four Performance Standards and the Educator’s attainment of goals set forth in the Educator Plan, as follows:
