Volume of TIPS Sales Nothing in this Agreement or any TIPS communication may be construed as a guarantee that TIPS or TIPS Members will submit any TIPS orders to Vendor at any time.
Contract Year A twelve (12) month period during the term of the Agreement commencing on the Effective Date and each anniversary thereof.
Sales, Etc (i) Sell, lease, transfer or otherwise dispose of any shares of common stock of any Significant Subsidiary of such Borrower, whether now owned or hereafter acquired by such Borrower, or permit any Significant Subsidiary of such Borrower to do so; provided, however, the limitation in this clause (i) shall not in any way restrict, and shall not apply to, any Specified Disposition; or (ii) sell, lease, transfer or otherwise dispose of (whether in one transaction or a series of transactions) or permit any of its Subsidiaries to sell, lease, transfer or dispose of (whether in one transaction or a series of transactions) assets located in the United States (other than any assets that are purported to be conveyed in connection with a Permitted Securitization but including assets purported to be conveyed pursuant to any sale leaseback transaction) having an aggregate book value (determined as of the date of such transaction for all such transactions since the date hereof) that is greater than 20% of the book value of all of the consolidated fixed assets of such Borrower, as reported on the most recent consolidated balance sheet of such Borrower prior to the date of such sale, lease, transfer or disposition to any entity other than such Borrower or any of its wholly owned direct or indirect Subsidiaries; provided, however, that the limitation in this clause (ii) shall not in any way restrict, and shall not apply to, (A) [reserved], (B) [reserved], or (C) the sale, lease, transfer or other disposition of any Borrower’s assets to another Borrower, a Subsidiary of another Borrower or a newly-formed Person to which all or substantially all of the assets and liabilities of such Borrowers or their Subsidiaries are being transferred, in each case under this clause (C), pursuant to a transaction permitted under subsection (c) below.
Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Mail Order Catalog Warnings In the event that, the Settling Entity prints new catalogs and sells units of the Products via mail order through such catalogs to California consumers or through its customers, the Settling Entity shall provide a warning for each unit of such Product both on the label in accordance with subsection 2.4 above, and in the catalog in a manner that clearly associates the warning with the specific Product being purchased. Any warning provided in a mail order catalog shall be in the same type size or larger than other consumer information conveyed for such Product within the catalog and shall be located on the same display page of the item. The catalog warning may use the Short-Form Warning content described in subsection 2.3(b) if the language provided on the Product label also uses the Short-Form Warning.
C1 Contract Price In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Contract Quantity The Contract Quantity during each Contract Year is the amount set forth in the applicable Contract Year in Section D of the Cover Sheet (“Delivery Term Contract Quantity Schedule”), which amount is inclusive of outages.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.