Vendor’s Resellers as Related to This Agreement
License to Customer Vendor grants to Customer, a perpetual, irrevocable, royalty free license, solely for the Customer’s internal business purposes, to use, copy, modify, display, perform (by any means), transmit and prepare derivative works of any Vendor IP embodied in or delivered to Customer in conjunction with the Work Product. The foregoing license includes the right to sublicense third parties, solely for the purpose of engaging such third parties to assist or carryout Customer’s internal business use of the Work Product. Except for the preceding license, all rights in Vendor IP remain in Vendor.
Data Access Services State Street agrees to make available to the Fund the Data Access Services subject to the terms and conditions of this Addendum and such data access operating standards and procedures as may be issued by State Street from time to time. The Fund shall be able to access the System to (i) originate electronic instructions to State Street in order to (a) effect the transfer or movement of cash or securities held under custody by State Street or (b) transmit accounting or other information (the transactions described in (i)(a) and (i)(b) above are referred to herein as “Client Originated Electronic Financial Instructions”), and (ii) access data for the purpose of reporting and analysis, which shall all be deemed to be Data Access Services for purposes of this Addendum.
Verizon OSS Services Access to Verizon Operations Support Systems functions. The term “Verizon OSS Services” includes, but is not limited to: (a) Verizon’s provision of ECI Usage Information to ECI pursuant to Section 8.3 of this Attachment; and, (b) “Verizon OSS Information”, as defined in Section 8.1.4 of this Attachment.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Customer Focus Is dedicated to meeting the expectations and requirements of internal and external customers; gets first hand customer information and uses it for improvements in products and services; acts with customers in mind; establishes and maintains effective relationships with customers and gains their trust and respect
The Web Services E-Verify Employer Agent agrees to, consistent with applicable laws, regulations, and policies, commit sufficient personnel and resources to meet the requirements of this MOU.
TAX SUPPORT SERVICES BNY Mellon shall provide the following tax support services for each Fund: Provide various data and reports as agreed upon in the SLDs to support TRP’s tax reporting and tax filing obligations, including: · Wash sales reporting; · QDI reporting; · DRD reporting; · PFIC analysis; · Straddle analysis; · Paydown adjustments; · Equalization debit adjustments · Tax compliance under §851, §817(h); · Foreign bond sale analysis (§988); · Troubled debt analysis; · Estimation of income for excise tax purposes; · Swap analysis; · Inflation adjustments; · §1256 adjustments; · Market discount analysis; OID adjustments; · CPDI analysis; · Shareholder tax reporting information (e.g. FTC, UGG income, foreign source income by country, exempt income by state); Provide data, and reports based on such data, maintained by BNY Mellon on its fund accounting platform as reasonably requested by TRP to support TRP’s obligations to comply with requests from tax authorities and TRP’s tax reporting and tax filing obligations. Assist with other tax-related data needs as mutually agreed upon in writing from time-to-time.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
Vendor’s Resellers as Related to This Agreement Vendor’s Named Resellers (“Resellers”) under this Agreement shall comply with all terms and conditions of this agreement and all addenda or incorporated documents. All actions related to sales by Authorized Vendor’s Resellers under this Agreement are the responsibility of the awarded Vendor. If Resellers fail to report sales to TIPS under your Agreement, the awarded Vendor is responsible for their contractual failures and shall be billed for the fees. The awarded Vendor may then recover the fees from their named reseller. If there is a dispute between the awarded Vendor and TIPS Member, TIPS or its representatives may, at TIPS sole discretion, assist in conflict resolution if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded Vendor’s TIPS project files, documentation and correspondence related to the requesting TIPS Member’s order. If there are confidentiality requirements by either party, TIPS shall comply to the extent permitted by law. The TIPS Solicitation which resulted in this Vendor Agreement, whether a Request for Proposals, the Request for Competitive Sealed Proposals or Request for Qualifications solicitation, or other, the Vendor’s response to same and all associated documents and forms made part of the solicitation process, including any addenda, are hereby incorporated by reference into this Agreement as if copied verbatim. THE SECTON HEADERS OR TITLES WITHIN THIS DOCUMENT ARE MERELY GUIDES FOR CONVENIENCE AND ARE NOT FOR CLASSIFICATION OR LIMITING OF THE RESPONSIBILITES OF THE PARTIES TO THIS DOCUMENT. Texas governmental entities are prohibited from doing business with companies that fail to certify to this condition as required by Texas Government Code Sec. 2270. By executing this agreement, you certify that you are authorized to bind the undersigned Vendor and that your company (1) does not boycott Israel; and (2) will not boycott Israel during the term of the Agreement. You certify that your company is not listed on and does not and will not do business with companies that are on the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf You certify that if the certified statements above become untrue at any time during the life of this Agreement that the Vendor will notify TIPS within three (3) business day of the change by a letter on Vendor’s letterhead from and signed by an authorized representative of the Vendor stating the non-compliance decision and the TIPS Agreement number and description at: Attention: General Counsel ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx, XX,00000 And by an email sent to xxxx@xxxx-xxx.xxx The undersigned Vendor agrees to maintain the below minimum insurance requirements for TIPS Contract Holders: When the Vendor or its subcontractors are liable for any damages or claims, the Vendor’s policy, when the Vendor is responsible for the claim, must be primary over any other valid and collectible insurance carried by the Member. Any immunity available to TIPS or TIPS Members shall not be used as a defense by the contractor's insurance policy. The coverages and limits are to be considered minimum requirements and in no way limit the liability of the Vendor(s). Insurance shall be written by a carrier with an A-; VII or better rating in accordance with current A.M. Best Key Rating Guide. Only deductibles applicable to property damage are acceptable, unless proof of retention funds to cover said deductibles is provided. "Claims made" policies will not be accepted. Vendor’s required minimum coverage shall not be suspended, voided, cancelled, non-renewed or reduced in coverage or in limits unless replaced by a policy that provides the minimum required coverage except after thirty (30) days prior written notice by certified mail, return receipt requested has been given to TIPS or the TIPS Member if a project or pending delivery of an order is ongoing. Upon request, certified copies of all insurance policies shall be furnished to the TIPS or the TIPS Member. • Orders: All Vendor orders received from TIPS Members must be emailed to TIPS at tipspo@tips- xxx.xxx. Should a TIPS Member send an order directly to the Vendor, it is the Vendor’s responsibility to forward a copy of the order to TIPS at the email above within 3 business days and confirm its receipt with TIPS. • Vendor Encouraging Members to bypass TIPS agreement: Encouraging TIPS Members to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program. • Order Confirmation: All TIPS Member Agreement orders are approved daily by TIPS and sent to the Vendor. The Vendor should confirm receipt of orders to the TIPS Member (customer) within 3 business days. • Vendor custom website for TIPS: If Vendor is hosting a custom TIPS website, updated pricing when effective. TIPS shall be notified when prices change in accordance with the award.
