Health, Safety and Security 22.2.1 The University and the Association agree to promote safe, secure and healthy working conditions and procedures, and to encourage Members to adopt and follow sound health, safety and security procedures in the performance of their work.
Singular Includes the Plural; Gender; Title Reference Whenever the singular number is used in this Contract and when required by the context, the same shall include the plural, and the use of any gender, be it masculine, feminine or neuter, shall include all of the genders, and the word “person” or “entity” shall include corporation, firm, partnership, or any other combination or association. The use of the title “Bidder”, “Vendor”, “Contractor” or “Consultant” within this contract or associated bid documents shall be deemed interchangeable and shall refer to the person or entity with whom the City of Sparks is contracting for the service or product referenced within this contract.
Pupil Safety and Fingerprinting CONTRACTOR shall comply with all provisions of the Education Code which protect the safety of any pupil that may come in contact with employees of the CONTRACTOR. Pursuant to Education Code section 45125.1, CONTRACTOR shall conduct criminal background checks of ALL employees of CONTRACTOR assigned to the PROJECT site, and shall certify that no employees who have been convicted of serious or violent felonies, as specified in Education Code Section 45125.1, will have contact with pupils, by utilizing the General Certification Regarding Background Checks Form. As part of such certification, CONTRACTOR must provide the District with a list of all employees providing services pursuant to this Agreement, and designate which sites such employees will be assigned. In performing the services set forth in this Agreement, CONTRACTOR shall not utilize any employees who are not included on the above-referenced list. At District’s sole discretion, District may make a finding, as authorized under Education Code section 45125.1, that CONTRACTOR’s employees will have only “limited contact” with pupils. In accordance with Education Code Section 45125.2, a CONTRACTOR performing construction, reconstruction, rehabilitation or repair services to a school facility shall not be required to perform Section 45125.1 background checks of all employees assigned to the PROJECT site if such CONTRACTOR installs a physical barrier at the worksite to limit employee contact with pupils and/or provides continual supervision and monitoring of all employees of the CONTRACTOR by an employee of the CONTRACTOR whom the Department of Justice has ascertained has not been convicted of a violent or serious felony. Such CONTRACTOR shall certify to the District its compliance with one of the aforementioned alternatives under Education Code Section 45125.2 pertaining to pupil safety with the form entitled CONSTRUCTION CONTRACTOR CERTIFICATION REGARDING BACKGROUND CHECKS which is on file at the Administrative Office of the DISTRICT. Contractor’s failure to comply with the law or Article VI, Paragraph 4 of this Agreement shall be considered a material breach of this Agreement upon where this Agreement may be terminated, at District’s sole discretion, without any further compensation to Contractor.
Fair and Equitable Treatment and Full Protection and Security 1. Each Party shall accord fair and equitable treatment and full protection and security in accordance with customary international law in its territory to investment of investors of the other Party. 2. For greater certainty, (a) the concepts of "fair and equitable treatment" and "full protection and security" do not require additional treatment to that required under the minimum standard of treatment of aliens in accordance with the standard of customary international law; (b) a determination that there has been a breach of another provision of this Agreement or another international agreement does not imply that the minimum standard of treatment of aliens has been breached; (c) "fair and equitable treatment" includes the prohibition against denial of justice in criminal, civil, or administrative proceedings in accordance with the general accepted principles of customary international law; and (d) the "full protection and security" standard does not imply, in any case, a better treatment to that accorded to nationals of the Party where the investment has been made.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Data Protection and Security A. In this Agreement the following terms shall have the meanings respectively ascribed to them:
Department of Homeland Security Points of view or opinions expressed in this document are those of the authors and do not necessarily represent the official position or policies of FEMA's Grant Programs Directorate or the U.S.
Background Screening and Security 14 These General Contract Conditions supersede and replace in their entirety all General Contract Conditions, Form PUR 1000, which is incorporated by reference in Rule 60A-1.002, Florida Administrative Code (F.A.C.)
Safety and Security Contractor is responsible for maintaining safety in the performance of this Contract. Contractor shall be responsible for complying with the District’s rules and regulations pertaining to safety, security, and driving on school grounds, particularly when children are present.
Solid Waste The Licensee shall have to make arrangements for disposal of solid waste, which shall be got removed from the premises on a daily basis to ensure perfect cleanliness as per Corporation of Chennai Norms. The Licensee shall have to make arrangements for the solid waste to be separated into glass, plastic and food waste and for the food waste to be treated in a shredder to be converted into a paste. The waste shall need to be expelled into a common dump or waste area provided/ indicated by CMRL. If solid waste is found disposed of on CMRL land or premises a penalty/fine of Rs.2000/- shall be imposed by CMRL for each occasion.
