WORK OR SERVICES PERFORMED BY OTHERS Sample Clauses

WORK OR SERVICES PERFORMED BY OTHERS. Qwest is responsible for ensuring that any work or services performed at the site by Qwest or its other vendors or contractors shall not interfere with Corvis' performance of Services. Corvis agrees to reasonably cooperate and not interfere with the performance of services by Qwest or its other vendors and contractors. Corvis shall have no responsibility or liability with respect to such work or services performed by others. If Qwest or its other vendors or contractors fail to timely complete the site readiness or if Qwest's or its other vendors' or contractors' work interferes with Corvis' performance, and Corvis notifies Qwest of such failures or interference, the scheduled completion date of Corvis' Services under this Agreement shall be extended as necessary to compensate for such delay or interference.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
WORK OR SERVICES PERFORMED BY OTHERS. The scheduling and performance of Corvis' services shall be carried out in accordance with and subject to the schedules and priorities established by Customer. Corvis shall have no responsibility or liability with respect to such work or services performed by others. If Customer or its other vendors or contractors fail to timely complete the site readiness or if Customer's or its other vendors' or contractors' work interferes with Corvis' performance, the scheduled completion date of Corvis' Services under this Agreement shall be extended as necessary to compensate for such delay or interference.
Sample 1

Related to WORK OR SERVICES PERFORMED BY OTHERS

  • Services to be performed by Contractor In consideration of the payments set forth herein and in Exhibit “B,” Contractor shall perform services for County in accordance with the terms, conditions and specifications set forth herein and in Exhibit “A.”

  • Services Performance All services are performed using generally recognized commercial practices and standards. Customer agrees to provide prompt notice of any such service concerns and HP will re-perform any service that fails to meet this standard.

  • Services to be Performed by Consultant The Parties agree that Consultant shall perform such services as are set forth and described in Exhibit A - Scope of Services and incorporated herein as if written word for word. All services provided by Consultant hereunder shall be performed in accordance with the degree of care and skill ordinarily exercised under similar circumstances by competent members of their profession. In case of conflict in the language of Exhibit A and this Agreement, this Agreement shall govern and control. Deviations from the Scope of Services or other provisions of this Agreement may only be made by written agreement signed by all Parties to this Agreement.

  • Services to be Performed Subject always to the supervision of Fund’s Board of Trustees and the Manager, Sub-Adviser will furnish an investment program in respect of, make investment decisions for, and place all orders for the purchase and sale of securities for the portion of the Fund’s investment portfolio allocated to the Sub-Adviser by the Manager, all on behalf of the Fund. In the performance of its duties, Sub-Adviser will satisfy its fiduciary duties to the Fund, will monitor the Fund’s investments, and will comply with the provisions of the Fund’s Declaration of Trust and By-laws, as amended from time to time, and the stated investment objectives, policies and restrictions of the Fund. Manager will provide Sub-Adviser with current copies of the Fund’s Declaration of Trust, By-laws, prospectus and any amendments thereto, and any objectives, policies or limitations not appearing therein as they may be relevant to Sub-Adviser’s performance under this Agreement. Sub-Adviser and Manager will each make its officers and employees available to the other from time to time at reasonable times to review investment policies of the Fund and to consult with each other regarding the investment affairs of the Fund. Sub-Adviser will report to the Board of Trustees and to Manager with respect to the implementation of such program. The Sub-Adviser will vote all proxies solicited by or with respect to the issuers of securities which assets of the Fund’s investment portfolio allocated by the Adviser to the Sub-Adviser are invested, consistent with its proxy voting guidelines and based upon the best interests of the Fund. The Sub-Adviser will maintain appropriate records detailing its voting of proxies on behalf of the Fund and upon reasonable request will provide a report setting forth the proposals voted on and how the Fund’s shares were voted, including the name of the corresponding issuers. Sub-Adviser is authorized to select the brokers or dealers that will execute the purchases and sales of portfolio securities for the Fund, and is directed to use its commercially reasonable efforts to obtain best execution, which includes most favorable net results and execution of the Fund’s orders, taking into account all appropriate factors, including price, dealer spread or commission, size and difficulty of the transaction and research or other services provided. Sub-Adviser may select itself as a broker, in an agency capacity, to execute transactions in portfolio securities for the Fund in accordance with policies and procedures adopted by the Fund’s Board of Trustees from time to time. It is understood that the Sub-Adviser will not be deemed to have acted unlawfully, or to have breached a fiduciary duty to the Fund, or be in breach of any obligation owing to the Fund under this Agreement, or otherwise, solely by reason of its having caused the Fund to pay a member of a securities exchange, a broker or a dealer (including the Sub-Adviser’s internal broker-dealer) a commission for effecting a securities transaction for the Fund in excess of the amount of commission another member of an exchange, broker or dealer would have charged if the Sub-Adviser determined in good faith that the commission paid was reasonable in relation to the brokerage or research services provided by such member, broker or dealer, viewed in terms of that particular transaction or the Sub-Adviser’s overall responsibilities with respect to its accounts, including the Fund, as to which it exercises investment discretion. In addition, if in the judgment of the Sub-Adviser, the Fund would be benefited by supplemental services, the Sub-Adviser is authorized to pay spreads or commissions to brokers or dealers furnishing such services in excess of spreads or commissions that another broker or dealer may charge for the same transaction, provided that the Sub-Adviser determined in good faith that the commission or spread paid was reasonable in relation to the services provided. The Sub-Adviser will properly communicate to the officers and trustees of the Fund such information relating to transactions for the Fund as they may reasonably request. In no instance will portfolio securities be purchased from or sold to the Manager, Sub-Adviser or any affiliated person of either the Fund, Manager, or Sub-Adviser, except as may be permitted under the 1940 Act; Sub-Adviser further agrees that it: (a) will use the same degree of skill and care in providing such services as it uses in providing services to fiduciary accounts for which it has investment responsibilities; (b) will conform to all applicable Rules and Regulations of the Securities and Exchange Commission in all material respects and in addition will conduct its activities under this Agreement in accordance with any applicable regulations of any governmental authority pertaining to its investment advisory activities; (c) will report regularly to Manager and to the Board of Trustees of the Fund and will make appropriate persons available for the purpose of reviewing with representatives of Manager and the Board of Trustees on a regular basis at reasonable times the management of the Fund, including, without limitation, review of the general investment strategies of the Fund with respect to preferred securities, the performance of the Fund’s investment portfolio allocated to preferred securities in relation to standard industry indices and general conditions affecting the marketplace and will provide various other reports from time to time as reasonably requested by Manager; and (d) will monitor the pricing of portfolio securities, and events relating to the issuers of those securities and the markets in which the securities trade in the ordinary course of managing the portfolio securities of the Fund, and will notify Manager promptly of any issuer-specific or market events or other situations that occur (particularly those that may occur after the close of a foreign market in which the securities may primarily trade but before the time at which the Fund’s securities are priced on a given day) that may materially impact the pricing of one or more securities in Sub-Adviser’s portion of the portfolio. In addition, Sub-Adviser will assist Manager in evaluating the impact that such an event may have on the net asset value of the Fund and in determining a recommended fair value of the affected security or securities; and (e) will prepare such books and records with respect to the Fund’s securities transactions for the portion of the Fund’s investment portfolio allocated to preferred securities as requested by the Manager and will furnish Manager and Fund’s Board of Trustees such periodic and special reports as the Board or Manager may reasonably request.

  • Services Provided Subcontractor agrees to complete the following: ____________ ___________________________________________________________ (“Services”).

  • Authorization to Perform Services The Consultant is not authorized to perform any services or incur any costs whatsoever under the terms of this Agreement until receipt of a written Notice to Proceed from the City.

  • Services Contractor Agrees to Perform Contractor agrees to perform the Services stated in Appendix A, “Scope of Services.” Officers and employees of the City are not authorized to request, and the City is not required to reimburse the Contractor for, Services beyond the Scope of Services listed in Appendix A, unless Appendix A is modified as provided in Section 11.5, “Modification of this Agreement.”

  • The Services The HSP agrees to provide the Services on the terms and conditions of this PFA including all of its Appendices and schedules.

  • Services to Other Clients Nothing herein contained shall limit the freedom of the Adviser or any affiliated person of the Adviser to render investment management and administrative services to other investment companies, to act as investment adviser or investment counselor to other persons, firms or corporations, or to engage in other business activities.

  • Data Necessary to Perform Services The Trust or its agent shall furnish to USBFS the data necessary to perform the services described herein at such times and in such form as mutually agreed upon.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!