Avoidable Delay definition

Avoidable Delay shall have the meaning given in Section 7.2.3 of these General Conditions. “Business Inclusion and Diversity Program” shall mean that program established in OSU Standard 03-010, Procurement Thresholds and Methods, and operated pursuant to the university’s Procurement and Contracts unit rules, policies and procedures.
Sample 1Sample 2Sample 3
Avoidable Delay shall have the meaning given in Section 7.2.3 of these General Conditions.
Sample 1Sample 2Sample 3
Avoidable Delay shall have the meaning given in Section 7.2.3 of these General Conditions. “Back-Up Documents” shall have the meaning given in Section 6.1.2 of these General
Sample 1Sample 2

Examples of Avoidable Delay in a sentence

  • Contractor shall not be granted an extension of time for any Avoidable Delay (also defined below).

  • Notwithstanding the foregoing, Contractor shall not be granted relief: (i) due to Contractor’s financial inability to perform; (ii) unless a Delay is an Unavoidable Delay and affects the Project’s or phase’s critical path as set forth in the applicable Construction Schedule, and then only to the extent such critical path is affected; or (iii) if a Delay would have resulted because of Contractor’s concurrent Avoidable Delay, notwithstanding the existence of an Unavoidable Delay.

  • If a delay for which Contractor seeks compensation under Article 10.02F is caused concurrently with either Avoidable Delay or Unavoidable Delay, then District is only responsible for that portion of any compensable delay which it caused in excess of such Avoidable Delay or Unavoidable Delay, provided Contractor is able to prove such apportionment.

  • Delay attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delay within the control of Contractor (that is, Avoidable Delay).

  • Such legislation, however, has stopped shy of the federal court ruling by not actually classifying interns as employees, avoiding the question oftripleC 13(2): 567-578, 2015 Intern Labor Rights payment altogether (Hickman and Thompson 2013).

  • In most cases the prosecutor will not seek to read the report, as it is not usually his/her practice to use the information contained 21 PBNI Annual Report 2005/6.22 Criminal Justice Inspection NI May 2006 Avoidable Delay, a thematic inspection, Belfast.therein to influence the sentence.

  • If such extension of time for Avoidable Delay is not granted, the provisions of the paragraph "Right of Owner to Terminate Contract" of these General Conditions will be followed.

  • Design-Builder shall not be granted an extension of time for any Avoidable Delay (also defined below).

  • Belfast: NIACRO.CJINI (Criminal Justice Inspection Northern Ireland) (2010) Avoidable Delay.

  • Thus, the Court will not withdraw its referral to Judge Hacker of non-dispositive pretrial matters in this case.

Related to Avoidable Delay

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • avoidable costs means those costs which would not be incurred by the Licensee if he did not supply the consumers in question, including (but with due regard to the timing thereof all relevant future outlays affected by the decision to supply; and"terms"means all the terms on which a supply of gas is provided or offered, whether as respects charges, methods of payment or otherwise.

  • Avoidable Cost Rate means a component of the Market Seller Offer Cap calculated in accordance with Tariff, Attachment DD, section 6. “Balancing Congestion Charges” shall be equal to the sum of congestion charges collected from Market Participants that are purchasing energy in the Real-time Energy Market minus [the sum of congestion charges paid to Market Participants that are selling energy in the Real-time Energy Market plus any congestion charges calculated pursuant to the Joint Operating Agreement between the Midcontinent Independent Transmission System Operator, Inc. and PJM Interconnection, L.L.C. (PJM Rate Schedule FERC No. 38), plus any congestion charges calculated pursuant to the Joint Operating Agreement Among and Between New York Independent System Operator Inc. and PJM Interconnection, L.L.C. (PJM Rate Schedule FERC No. 45), plus any congestion charges calculated pursuant to agreements between the Office of the Interconnection and other entities, plus any charges or credits calculated pursuant to Operating Agreement, Schedule 1, section 3.8, and the parallel provisions of Tariff, Attachment K-Appendix, section 3.8, as applicable)].

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.

  • Deactivation Avoidable Cost Credit means the credit paid to Generation Owners pursuant to Tariff, Part V, section 114.

  • Deactivation Avoidable Cost Rate means the formula rate established pursuant to Tariff, Part V, section 115 of this Tariff.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Non-Performing Party The Party who is in breach of, or is otherwise failing to perform, its obligations under this Agreement.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Affordable Rent means a rent which does not exceed eighty per centum (80%) of the market rent (inclusive of service charges) for an equivalent property of the relevant size and location such rent to be assessed and set in accordance with the applicable requirements of Legislation and of the Rent Standard;

  • Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Voidable Transfer has the meaning set forth in Section 17.7.

  • Collateral Requirement means the requirement that:

  • Force Majeure Event means an event beyond the reasonable control of any party including an outbreak of a serious disease or epidemic, or quarantine or other public health emergencies, fire, flood, earthquake, explosion or other casualty or accident or act of God, or war or other violence, strike, lock-out, labour dispute, acts of any governmental body, war, insurrection, sabotage, embargo, interruption of or delay in transportation, unavailability of or interruption or delay in telecommunications or inability to obtain raw materials, supplies or power.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Non-Performing Equipment Note means an Equipment Note issued pursuant to an Indenture that is not a Performing Equipment Note.

  • Automatic tabulating equipment means apparatus that automatically examines

  • Disallowed costs means those charges determined to be unallowable, in accordance with the applicable Federal statutes, regulations, or the terms and conditions of the Federal award. (2 CFR 200.31 and 45 CFR 75.2)

  • Disallowed means, with respect to any Claim, a Claim or any portion thereof that: (a) has been disallowed by a Final Order; (b) is listed in the Schedules as zero or as contingent, disputed, or unliquidated and as to which no Proof of Claim or request for payment of an Administrative Claim has been timely Filed or deemed timely Filed with the Bankruptcy Court pursuant to either the Bankruptcy Code or any Final Order of the Bankruptcy Court or otherwise deemed timely Filed under applicable law or the Plan; (c) is not listed in the Schedules and as to which no Proof of Claim or request for payment of an Administrative Claim has been timely Filed or deemed timely Filed with the Bankruptcy Court pursuant to either the Bankruptcy Code or any Final Order of the Bankruptcy Court or otherwise deemed timely Filed under applicable law or the Plan; (d) has been withdrawn by agreement of the applicable Debtor and the Holder thereof; or (e) has been withdrawn by the Holder thereof.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • An undependable Supplier/s under contract means any Supplier who do not accept the purchase order or who delays the supply of required quantities beyond the permitted delays with liquidated damages

  • Landlord’s Work means the work of constructing the Tenant Improvements.