Substantial Completion Date means the date on which Substantial Completion occurs.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Project Completion Date means the date on which the Completion Certificate is issued;
Target Completion Date has the meaning given such term in Section 3.3(b).
Final Completion Date means the date on which Final Completion occurs.
Subproject means a development activity proposed by a Beneficiary under Part A.2 (d) of the Project and financed or to be financed through a Subproject Grant (as hereinafter defined) made out of the proceeds of the Development Credit;
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.
Development Milestone Event shall have the meaning set forth in Section 9.2(a).
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.
Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Project Milestone means the project milestone set forth in Schedule-J;
Base Building Work means the base building work for the Building as described in this Manual.
Phase II Study means a human clinical trial, for which the primary endpoints include a determination of dose ranges and/or a preliminary determination of efficacy in patients being studied as described in 21 C.F.R. § 312.21(b) (FDCA), as amended from time to time, and the foreign equivalent thereof.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Subprojects means more than one such Subproject.
Phase III means Phase I (or Phase I/II), Phase II (or Phase II/III) and Phase III clinical trials, respectively, in each case as prescribed by applicable FDA IND Regulations, or any corresponding foreign statutes, rules or regulations.
Phase 2 Clinical Trial means a human clinical trial of a product in any country that would satisfy the requirements of 21 C.F.R. 312.21(b) and is intended to explore a variety of doses, dose response, and duration of effect, and to generate initial evidence of clinical safety and activity in a target patient population, or a similar clinical study prescribed by the relevant Regulatory Authorities in a country other than the United States.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Project Milestones means the project milestones set forth in Schedule-G;