We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Building Architect definition

Building Architect means “Ai / Xxxxx Xxxxxxx Architectural” and all other architects, structural engineers, mechanical engineers, design build specialists, and other design professionals retained by Landlord and needed to design the Building Shell, the Site Improvements, Additional Site Improvements, and/or the Demolition, each of whom shall be duly licensed by the State of California and in good professional standing.
Sample 1Sample 2
Building Architect means the architect designated by the Lessor to monitor the status of the Building and the work of any nature whatsoever which may be carried out in the Building.
Sample 1Sample 2
Building Architect. Good, Fulton and Farrell Architxxxx.
Sample 1

Examples of Building Architect in a sentence

  • Except in extraordinary circumstances which would reasonably require an exception, all work to be performed in the Building shall be performed by the Building Contractor on the basis of plans and drawings prepared by the Building Architect.

  • Before proceeding with any Tenant’s Changes, Tenant shall advise Landlord thereof and arrange a meeting with the Building Manager, the Building Architect, and/or the Building Contractor, as required by Landlord in relation to the scope of the proposed Changes.

  • Contact ideals@uq.edu.au for more information.o Cultural Inclusion Council and the Disability Inclusion Group: any items that you would like brought to the attention send to ideals@uq.edu.au.o Australian Workplace Equality Index and awaiting benchmarking with other national institutions.

  • Such notice shall be accompanied by an occupancy permit and a certificate from the Building Architect stating that remaining punchlist items can be completed within fifteen (15) days and will not materially interfere with Tenant's business.

  • Landlord shall then cause the Building Architect to prepare and deliver to Tenant, for Tenant’s approval, proposed final plans and specifications for such work, which are logical evolutions of the preliminary plans approved by Tenant, on or before the date for completion of such items specified in the Project Schedule.

  • On or before the date specified in the Project Schedule (Exhibit C-1), Landlord shall cause the Building Architect to prepare and deliver to Tenant proposed schematic / preliminary Plans and Specifications for the Building Shell, Site Improvements and Additional Site Improvements.

  • The Shareholder hereby indemnifies and holds harmless the Corporation, its employees, officers and directors, the Building Engineer, the Building Architect, the Managing Agent, and all other shareholders and residents of the Building (the “tenants”) against any damages suffered to persons or property as a result of the Work.

  • At least five business days prior to the commencement of the Work, the Shareholder shall give written notice, substantially in the form attached hereto as Exhibit “B”, to the Building Architect, the Building Engineer, the Superintendent of the Building, and the Managing Agent.

  • The Building Architect will measure the Premises based on the Final Working Drawings and Specifications, and Landlord and Tenant will confirm the exact area of the Premises, including usable and rentable square footage, in writing prior to the Rent Commencement Date.

  • Architects means the Building Architect and the Tenant Improvement Architect.


More Definitions of Building Architect

Building Architect. Xxx Xxxxxxx Xxxxxx Xxxxxx Xxxxxxx 000 Xxxxxxxxx Xxxxxx Xxx Xxxx, XX 00000 (000) 000-0000 Building Engineer: Xxxxxxx Xxxxxxx Xxxxxxxxx Associates 0 Xxxx Xxxxx Xxx Xxxx, XX 00000 (000) 000-0000 Building Expediter: Xxxxxx Ansersen (Required by FCMA) JAM Consultants 000 Xxxx 00/xx/ Xxxxxx, 0/xx/ Xxxxx Xxx Xxxx, XX 00000 (000) 000-0000 FCMA Representative: Xxxxxxx Flocks Forest City Xxxxxx Companies 0 XxxxxXxxx Xxxxxx Xxxxx Xxxxxxxx, XX 00000 (000) 000-0000 The use of any other consultants must be approved by (FCMA), which approval will not be unreasonably withheld or delayed. In the event other consultants are used; it is required they comply with the following.
Sample 1
Building Architect means Grad Associates, PA or other licensed architect or architectural firm selected by the Developer and reasonably approved by the Agency to design the Private Improvements.
Sample 1

Related to Building Architect

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.

  • Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.

  • Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Building Contractor means the building contractor or developer appointed or to be appointed by the Grant Recipient in respect of a Firm Scheme; Business Day means any day other than a Saturday, Sunday or a statutory Bank Holiday in England;

  • Tenant Improvements Defined in Exhibit B, if any.

  • Building Area means the only area upon which the erection and use of buildings and structures shall be permitted but may include areas of Landscaped Open Space.

  • Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.

  • Building Common Areas means with respect to the Tower, the areas, facilities and amenities specified in Schedule [E] which are to be used and enjoyed in common with all the other Apartment Acquirers of the Units in the Building; and

  • Architect/Engineer (A/E means a person registered as an architect pursuant to Tex. Occ. Code Ann., Ch. 1051, as a landscape architect pursuant to Tex. Occ. Code Ann., Ch. 1052, a person licensed as a professional engineer pursuant Tex. Occ. Code Ann., Ch. 1001, and/or a firm employed by Owner or Design-Build Contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Building Drain means that part of the lowest horizontal piping of a drainage system which receives the discharge from soil, waste, and other drainage pipes inside the walls of the building and conveys it to the building sewer, beginning five (5) feet (1.5 meters) outside the inner face of the building wall.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth).

  • New Building ’ means a new construction to house a complete motor vehicle as- sembly process, where that construction includes the pouring or construction of a new foundation and floor, the erection of a new frame and roof, and the instal- lation of new plumbing and electrical and other utilities;

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • The Building means any building of which the Property forms part.

  • Structural Engineer means the Engineer appointed or to be appointed from time to time by Promoter for the preparation of the structural design and drawings of the buildings .

  • Building Square Footage or "BSF" means the square footage of assessable internal living space of a Unit, exclusive of any carports, walkways, garages, overhangs, patios, enclosed patios, detached accessory structure, other structures not used as living space, or any other square footage excluded under Government Code Section 65995 as determined by reference to the Building Permit for such Unit.

  • Building means any structure used or intended for supporting or sheltering any use or occupancy;

  • Outbuilding means and refer to structures such as (by way of example and not limitation) storage buildings, sheds, greenhouses, gazebos and other Roofed Structures.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Construction Consultant means a third-party architect or engineer selected and retained by Funding Lender, at the cost and expense of Borrower, to monitor the progress of construction of the Project and to inspect the Improvements to confirm compliance with this Borrower Loan Agreement.

  • Professional land surveyor means a professional land surveyor licensed under ch. 443.

  • Building construction means any physical activity on the site involved in the erection of a structure, cladding, external finish, formwork, fixture, fitting of service installation and the unloading of plant, machinery, materials or the like.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

Most Referenced Clauses

Most Referenced Definitions