Actual Damages has the meaning set forth in Section 12.4(C).
Special Damages shall have the meaning as set forth in Section 5.07.
Environmental Damages means all claims, demands, liabilities (including strict liability), losses, damages (including consequential damages), causes of action, judgments, penalties, fines, costs and expenses (including reasonable fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, contingent or otherwise, matured or unmatured, known or unknown, direct or indirect, foreseeable or unforeseeable, made, incurred, suffered or brought at any time and from time to time and arising in whole or in part from:
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Seller Damages shall have the meaning given to such term in Section 14.3.
Buyer Losses shall have the meaning set forth in Section 8.2.
Direct Damage has the meaning given to it in clause 26.2;
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Indirect Losses means loss of profits, loss of production, loss of business, loss of business opportunity, or any claim for consequential loss or for indirect loss of any nature;
Direct Losses means all damages, losses, liabilities, penalties, fines, assessments, claims, actions, costs, expenses (including the cost of legal or professional services, legal costs being on a substantial indemnity basis), proceedings, demands and charges whether arising under statute, contract or at common law, except Indirect Losses.
Adverse Consequences means all actions, suits, proceedings, hearings, investigations, charges, complaints, claims, demands, injunctions, judgments, orders, decrees, rulings, damages, dues, penalties, fines, costs, amounts paid in settlement, Liabilities, obligations, Taxes, liens, losses, expenses, and fees, including court costs and reasonable attorneys' fees and expenses.
Material Damage and “Materially Damaged” means damage which, in Seller’s reasonable estimation, exceeds $500,000.00 to repair or which, in Seller’s reasonable estimation, will take longer than ninety (90) days to repair.
Consequential Loss means loss of profits, anticipated loss of profit or revenue, loss of production, loss of business opportunity, loss of or damage to goodwill or reputation, loss of use or any other similar loss, but excludes:
Environmental Damage means any injury or damage to persons, living organisms or property (including offence to man’s senses) or any pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;
BRRD Liability means a liability in respect of which the relevant Write Down and Conversion Powers in the applicable Bail-in Legislation may be exercised.
Indemnifiable Damages shall have the meaning set forth in Section 9.1 herein.
Seller Losses has the meaning set forth in Section 10.2(a).
Third Party Claims has the meaning set forth in Section 11.1.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Licensee Indemnitees has the meaning set forth in Section 11.2.