Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Delay Event means:
(i) a tsunami, flood, cyclone, earthquake, bushfire or other act of nature;
(ii) riot, civil commotion, war, invasion or a terrorist act;
(iii) an imminent threat of an event in paragraphs (i) or (ii); or
(iv) compliance with any lawful direction or order by a Government Agency;
Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation:
(1) acts of God or of the public enemy,
(2) acts of the United States of America in either its sovereign or contractual capacity,
(3) acts of another contractor in the performance of a contract with the Government,
(4) fires,
(5) floods,
(6) epidemics,
(7) quarantine restrictions,
(8) strikes,
(9) freight embargoes,
(10) unusually severe weather, or
(11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.
ERISA Termination Event means (i) a “Reportable Event” described in Section 4043 of ERISA and the regulations issued thereunder (other than a “Reportable Event” not subject to the provision for 30-day notice to the PBGC under such regulations), or (ii) the withdrawal of a Borrower or any of its ERISA Affiliates from a “single employer” Plan during a plan year in which it was a “substantial employer”, both of such terms as defined in Section 4001(a) of ERISA, or (iii) the filing of a notice of intent to terminate a Plan or the treatment of a Plan amendment as a termination under Section 4041 of ERISA, or (iv) the institution of proceedings to terminate a Plan by the PBGC or (v) any other event or condition which might constitute grounds under Section 4042 of ERISA for the termination of, or the appointment of a trustee to administer, any Plan or (vi) the partial or complete withdrawal of a Borrower or any ERISA Affiliate of such Borrower from a “multiemployer plan” as defined in Section 4001(a) of ERISA.
Incipient Event of Termination means an event that but for notice or lapse of time or both would constitute an Event of Termination.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Potential Termination Event means an event which, with the passage of time or the giving of notice, or both, would constitute a Termination Event.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Forbearance Termination Event has the meaning set forth in Section 3(a) hereto.
Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of:
(1) any unreasonable delay by Tenant in approving the Plans;
(2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason;
(3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant;
(4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or
(5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.
Termination Events means each of the events specified in Clause 10.3 of this Contract.
Default Event means an event or circumstance which leads Operator to determine that a Venue User is or appears to be unable or likely to become unable to meet its obligations in respect of an Order or Transaction or to comply with any other obligation under an Agreement or Applicable Law.
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Severe Disruption Event means any event specified as such in the Final Terms.
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Company Termination Event has the meaning set forth in Section 10 hereof.
Exercise Termination Event (i) the Effective Time (as defined in the Merger Agreement) of the Merger; (ii) termination of the Merger Agreement in accordance with the provisions thereof if such termination occurs prior to the occurrence of an Initial Triggering Event, except a termination by Grantee pursuant to Section 8.1(d) of the Merger Agreement (unless the breach by Issuer giving rise to such right of termination is non-volitional); or (iii) the passage of 12 months after termination of the Merger Agreement if such termination follows the occurrence of an Initial Triggering Event or is a termination by Grantee pursuant to Section 8.1(d) of the Merger Agreement (unless the breach by Issuer giving rise to such right of termination is non-volitional) (provided that if an Initial Triggering Event continues or occurs beyond such termination and prior to the passage of such 12-month period, the Exercise Termination Event shall be 12 months from the expiration of the Last Triggering Event but in no event more than 18 months after such termination). The "Last Triggering Event" shall mean the last Initial Triggering Event to expire. The term "Holder" shall mean the holder or holders of the Option.
Non-Viability Event means the earlier of:
Catastrophic Event : means an unforeseen event of biotic or abiotic nature caused by human action that leads to important disturbances of agricultural production systems and forest structures, eventually causing important economic damage to the farming or forestry sectors;
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Additional Termination Event has the meaning specified in Section 5(b).
Event of Force Majeure means one of the following events:
Emergency Event means any situation arising from sudden and reasonably unforeseen natural disaster such as earthquake, flood, fire, or other acts of God, or other unforeseen events beyond the control of the portable engine or equipment unit operator, its officers, employees, and contractors that threatens public health and safety and that requires the immediate temporary operation of portable engines or equipment units to help alleviate the threat to public health and safety.
Terminating Event means any of the following events:
Swap Termination Event means any event defined as a “Swap Termination Event” in the Interest Rate Swap Agreement.
Complete Termination means a termination of the Fund's Rule 12b-1 plan for B-2 Shares involving the cessation of payments of the Distribution Fees, and the cessation of payments of distribution fees pursuant to every other Rule 12b-1 plan of the Fund for every existing or future B-Class-of-Shares (as hereinafter defined) and the Fund's discontinuance of the offering of every existing or future B-Class-of-Shares, which conditions shall be deemed satisfied when they are first complied with hereafter and so long thereafter as they are complied with prior to the earlier of (i) the date upon which all of the B-2 Shares which are Distributor Shares pursuant to Schedule I hereto shall have been redeemed or converted or (ii) May 31, 2005. For purposes of this Section 14.5, the term B-Class-of-Shares means each of the B-1 Class of Shares of the Fund, the B-2 Class of Shares of the Fund and each other class of shares of the Fund hereafter issued which would be treated as Shares under Schedule I hereto or which has substantially similar economic characteristics to the B-1 or B-2 Classes of Shares taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of the shares of such class. The parties agree that the existing C Class of Shares of the Fund does not have substantially similar economic characteristics to the B-1 or B-2 Classes of Shares taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares. For purposes of clarity the parties to this agreement hereby state that they intend that a new installment load class of shares which may be authorized by amendments to Rule 6(c)-10 under the 1940 Act will be considered to be a B-Class-of-Shares if it has economic characteristics substantially similar to the economic characteristics of the existing B-1 or B-2 Classes of Shares taking into account the total sale charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares and will not be considered to be a B-Class-of-Shares if it has economic characteristics substantially similar to the economic characteristics of the existing C Class of shares of the Fund taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares.