Connection Works Completion Period definition

Connection Works Completion Period means the period of time to complete the Connection Works;
Sample 1Sample 2Sample 3
Connection Works Completion Period means the period of time to complete the Connection Works as set out in the Offer Letter;
Sample 1

Examples of Connection Works Completion Period in a sentence

  • The Company shall use prudent and commercial endeavours to obtain all such Operational Consents as shall be required by the Company for the purposes of the Company's Connection Works during the Connection Works Completion Period.

  • Where an Operational Consent is delayed the Company shall notify the Customer accordingly, advising it of any delays and/or costs that will arise by reason of the delay in the issue of an Operational Consent, and the Connection Works Completion Period shall be extended pro rata for the delay.

  • Suggested wording – 20.9 Termination due to lack of Operational Consents ‘If an Operational Consent required by the Company is not obtained within a reasonable period of time to enable the Company complete the Company's Connection Works within the Connection Works Completion Period, then subject to the provisions of Clause 6.4 of the Connection Agreement, either Partythe Customer may terminate the Connection Agreement by notice to the other PartyCompany.

Related to Connection Works Completion Period

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Final Completion Date means the date on which Final Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Excavation work means the making of any man-made cavity, trench, pit or depression formed by cutting, digging or scooping;

  • Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.

  • Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.

  • Production Period is the period that for winter cereal advances commences October 1, 2021 and terminates September 30, 2023; for advances on all other field crops, honey, hogs, goats, sheep and lambs commences April 1, 2022 and terminates September 30, 2023; and for advances on cattle, continuous flow cattle, and bison commences on April 1, 2022 and terminates on March 31, 2024.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Work means any work in connection with⎯

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;