Construction Agency Person definition

Construction Agency Person means the Construction Agent, the Lessee, any contractor, subcontractor, adviser, architect, engineer, developer, employee, attorney-in-fact or agent with respect to the Property and any other Person that the Construction Agent directly or indirectly supervises, hires or otherwise permits to engage in any Work with respect to the Property, any portion thereof or any Improvements thereto, and any Affiliate of any of the foregoing.
Sample 1Sample 2
Construction Agency Person means Lessee, Construction Agent, the Prime Contractor, the Architect, the General Contractor, any other contractor or subcontractor or other Person directly or indirectly performing work or providing services or materials on the Property, or relating to the Construction or the Properties, through and including the period ending on the Completion Date (regardless of when such Person commenced performing such work or providing such services or materials, including any period prior to the Documentation Date), and all of their respective officers, directors, shareholders, partners, employees, agents, consultants (on the Properties), service-providers (on the Properties), successors and assigns, and any Person controlled by any of the foregoing.
Sample 1
Construction Agency Person is defined in Section 5.3(c) of the Construction Agency Agreement.
Sample 1Sample 2

Examples of Construction Agency Person in a sentence

  • Notwithstanding anything to the contrary in this Agreement, the liability of the Indemnity Provider shall be limited to Claims caused by or resulting from the actions or failures to act of the Indemnity Provider or any other Construction Agency Person while the Indemnity Provider or any Construction Agency Person is in possession or control of the Property.

  • The Construction Agent may execute any of its duties under this Agreement by or through any Construction Agency Person; provided, however, that no such delegation shall limit or reduce in any way the Construction Agent’s duties, obligations or liabilities under this Agreement or any other Operative Agreement.

  • The Lessor may enter upon and repossess the Property by such means as are available at law or in equity, and may remove the Construction Agent, all Construction Agency Persons and all other Persons and any and all personal property and the equipment and personalty of each Construction Agency Person and severable Modifications from the Property.

  • To the extent any such Claim arising pursuant to Section 11.1 does not arise in connection with any Construction Agency Person's acts or a failure to act while any Construction Agency Person is in possession or control of the applicable Construction Period Property, then amounts paid by Advances prior to the Completion Date for such Claim shall be an Excluded Cost (such amounts paid shall be referred to as the "Excluded Indemnity Amount").

  • As between the Lessor, any other Indemnified Person and the Construction Agent, the Construction Agent shall be responsible for the acts and omissions of each Construction Agency Person.

  • With respect to the Property, the Construction Agent shall cause to be maintained a performance bond or comparable insurance program to manage the financial risks of failure to perform of each Construction Agency Person.

  • With respect to the Property, performance bond or comparable insurance program to manage the financial risks of failure to perform of each Construction Agency Person.

  • To the extent any such Claim arising pursuant to Section 11.1 does not arise in connection with any Construction Agency Person’s acts or a failure to act while any Construction Agency Person is in possession or control of the applicable Construction Period Property, then amounts paid by Advances prior to the Completion Date for such Claim shall be an Excluded Cost (such amounts paid shall be referred to as the “Excluded Indemnity Amount”).

  • Amounts payable during the Construction Period in payment of the indemnifications provided by the Lessee in Section 14(a) above (other than those described in subparagraph (11) of Section 14(a)) are limited to those matters as shall arise in connection with an act or failure to act on the part of the Construction Agent or a Construction Agency Person.


More Definitions of Construction Agency Person

Construction Agency Person means the Construction Agent, the Lessee, the Guarantors, any contractor, subcontractor, adviser, architect, engineer, developer, employee, attorney-in-fact or agent with respect to the Property and any other Person that the Construction Agent directly or indirectly supervises, hires or otherwise permits to engage in any Work with respect to the Property, any portion thereof or any Improvements thereto, and any Affiliate of any of the foregoing. “Construction Agent” shall mean AVDC, LLC (formerly, AVDC Inc.), an Ohio limited liability company, as the construction agent under the Agency Agreement. “Construction Agent Certificate” shall have the meaning given to such term in Section 5.17(b)(i)(A) of the Participation Agreement. “Construction Budget” shall mean the construction budget certified to the Agent detailing the cost of acquisition, installation, testing, constructing and developing the Property as determined by the Construction Agent in its reasonable, good faith judgment, as such budget may be amended, modified or supplemented from time to time in accordance with the terms of the Operative Agreements. “Construction Commencement Date” shall mean, with respect to Improvements, the Property Closing Date. “Construction Consultant” shall mean Xxxxx Fargo Real Estate Technical Services, a division of Xxxxx Fargo Bank, National Association, a national banking association. “Construction Contract” shall mean any contract entered into between the Construction Agent or the Lessee with (a) a Contractor for the construction of Improvements or any portion thereof on the Property, which shall be a maximum guaranteed price design-build agreement between the Construction Agent and the general contractor for the Property to complete construction of the Property in accordance with the Construction Budget on or prior to the Construction Period Termination Date, (b) an architect for the design of Improvements or any portion thereof on the Property, and (c) an engineer for engineering services regarding Improvements or any portion thereof on the Property. “Construction Documents” shall mean each of the Construction Contracts, the Construction Budget, the construction schedule, the Plans and Specifications and each and every other agreement or document related to any of the foregoing.
Sample 1

Related to Construction Agency Person

  • Construction Agent means the Lessee in its capacity as construction agent pursuant to the Construction Agency Agreement.

  • Procuring Agency PA means the implementing department which signs the contract

  • Auction Agency Agreement means the agreement between the Fund and the Auction Agent which provides, among other things, that the Auction Agent will follow the Auction Procedures for purposes of determining the Applicable Rate for shares of a series of MuniPreferred so long as the Applicable Rate for shares of such series is to be based on the results of an Auction.

  • Inspecting Agency means the agencies nominated and authorized by the competent authority for inspecting the material at the works of the supplier or at the designated place of inspection prescribed by the purchasing authority.

  • Contracting agency means the principal departments in the Executive Branch of the State Government, and any division, board, bureau, office, commission or other instrumentality within or created by such department, or any independent State authority, commission, instrumentality or agency, or any State college or university, any county college, or any local unit; with respect to this Contract, the contracting agency shall mean the Division;

  • Collection agency means a person that is directly engaged in collecting or attempting to collect a claim owed or due or asserted to be owed or due another, or repossessing or attempting to repossess a thing of value owed or due or asserted to be owed or due another person, arising out of an expressed or implied agreement. Collection agency includes an individual who, in the course of collecting, repossessing, or attempting to collect or repossess, represents himself or herself as a collection or repossession agency, or a person that performs collection activities that are regulated under article 9 of the occupational code, 1980 PA 299, MCL 339.901 to 339.920. Collection agency includes a person that furnishes or attempts to furnish a form or a written demand service that is represented to be a collection or repossession technique, device, or system to be used to collect or repossess claims, if the form contains the name of a person other than the creditor in a manner that indicates that a request or demand for payment is being made by a person other than the creditor even though the form directs the debtor to make payment directly to the creditor rather than to the other person whose name appears on the form. Collection agency includes a person that uses a fictitious name or the name of another in the collection or repossession of claims to convey to the debtor that a third person is collecting or repossessing or has been employed to collect or repossess the claim.

  • Environmental Protection Agency or "EPA" means the United States Environmental Protection Agency.

  • Environmental Protection Agency (EPA) means the United States Environmental Protection Agency.

  • Cooperating agency means any Federal agency other than a lead agency which has jurisdiction by law or special expertise with respect to any environmental impact involved in a proposal (or a reasonable alternative) for legislation or other major Federal action significantly affecting the quality of the human environment. The selection and responsibilities of a cooperating agency are described in Sec. 1501.6. A State or local agency of similar qualifications or, when the effects are on a reservation, an Indian Tribe, may by agreement with the lead agency become a cooperating agency.

  • Area agency on aging means the same as that term is defined in Section 62A-3-101.

  • (1) AGENCY.—The term agency’ means an execu- tive agency, as that term is defined in section 102 of title 31, United States Code.

  • escort agency means a person or business association who furnishes, offers to furnish, or advertises to furnish escorts as one of its primary business purposes for a fee, tip, or other consideration.

  • Procuring Agency means all State of New Mexico agencies, commissions, institutions, political subdivisions and local public bodies allowed by law to entertain procurements.

  • Calculation Agency Agreement means the Calculation Agency Agreement, dated as of December 21, 2006 between the Company and the Calculation Agent, as amended from time to time, or any successor calculation agency agreement.

  • General Special Servicer mean the Person performing the duties and obligations of special servicer with respect to the Mortgage Pool (exclusive of (A) any Serviced Loan Combination or related REO Property as to which a different Loan Combination Special Servicer has been appointed with respect thereto and (B) any Excluded Special Servicer Mortgage Loan or any related REO Property as to which an Excluded Mortgage Loan Special Servicer has been appointed with respect thereto).

  • Agency provider means an entity that directly employs at least one person in addition to the chief executive officer for the purpose of providing services for which the entity must be certified in accordance with rule 5123:2-2-01 of the Administrative Code.

  • Global Agency Agreement The global agency agreement between Xxxxxxx Mac and the Global Agent, dated as of the Closing Date.

  • State Contracting Agency means the department for which this contract is to be performed and for which the Commissioner or Authorized Designee acted in signing this contract.

  • Child support agency means the public agency responsible for child support

  • Auction Agent Agreement means the Initial Auction Agent Agreement unless and until a Substitute Auction Agent Agreement is entered into, after which "Auction Agent Agreement" shall mean such Substitute Auction Agent Agreement.

  • Rating Agency Inquiry As defined in Section 4.5(d).

  • Portfolio Supervisor means First Trust Advisors L.P. and its successors in interest, or any successor portfolio supervisor appointed as hereinafter provided." Section 1.01 (26) shall be added to read as follows:

  • Auction Agent means (a) the Administrative Agent or (b) any other financial institution or advisor employed by the Borrower (whether or not an Affiliate of the Administrative Agent) to act as an arranger in connection with any Discounted Term Loan Prepayment pursuant to Section 2.11(a)(ii); provided that the Borrower shall not designate the Administrative Agent as the Auction Agent without the written consent of the Administrative Agent (it being understood that the Administrative Agent shall be under no obligation to agree to act as the Auction Agent).

  • Maintenance Supervisor (Tradesperson) means an employee who has trade qualifications and has overall responsibility for maintenance at the place of employment and may be required to supervise other maintenance staff.

  • Construction Manager means a competent person responsible for the management of the physical construction processes and the coordination, administration and management of resources on a construction site;

  • Rating Agency Communication means, with respect to any action and any Securitization, any written communication intended for a Rating Agency, which shall be delivered at least ten (10) Business Days prior to completing such action, in electronic document format suitable for website posting to the 17g-5 information provider under the applicable Securitization Servicing Agreement.