Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.
construction site means a workplace where construction work is being performed;
Construction sign means a sign which identifies the architect, engineers, contractors and other individuals or firms involved with the construction of a building, or announces the character of the building or enterprise, which is erected during the building construction period.
Construction Completion means physical construction of a cleanup action component is complete.
Architect/Engineer (A/E means a person registered as an architect pursuant to Tex. Occ. Code Ann., Ch. 1051, as a landscape architect pursuant to Tex. Occ. Code Ann., Ch. 1052, a person licensed as a professional engineer pursuant Tex. Occ. Code Ann., Ch. 1001, and/or a firm employed by Owner or Design-Build Contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.
Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.
Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.
Construction project means the same as that term is defined in Section 38-1a-102.
Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.
Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;
Construction waste means solid waste which is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings, and other structures. Construction wastes include, but are not limited to lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, paving materials, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids and garbage are not construction wastes.
construction supervisor means a competent person responsible for supervising construction activities on a construction site;
Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.
Geotechnical engineer means a professional engineer registered with the Association of Professional Engineers, Geologists, and Geophysicists of the Northwest Territories and whose principal field of specialization is the design and construction of earthworks in a permafrost environment;
Construction Work means any work in connection with⎯
Project Engineer means the surveyor or engineer employed by or private
Professional land surveyor means a professional land surveyor licensed under ch. 443.
Land surveyor means the land surveyor appointed by the Seller, to act as such from time to time in respect of the Development or a member of a firm so appointed.
Survey means a survey of the Property prepared by a surveyor licensed in the State and satisfactory to Lender and the company or companies issuing the Title Insurance Policy, and containing a certification of such surveyor satisfactory to Lender.
Structural Engineer means the Engineer appointed or to be appointed from time to time by Promoter for the preparation of the structural design and drawings of the buildings .
Design-Builder means the Person selected pursuant to the RFP that enters into the Contract with the Department to design and construct the Project (also referred to as the “Design-Build Team”).
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Systems Engineering means preparing specifications, identifying and resolving interface problems, developing test requirements, evaluating test data, and supervising design.
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.
Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.