Initial Contractor definition

Initial Contractor means the contractor(s) or construction manager(s) which has entered into a written agreement with Borrower to perform all or any portion of the Initial Construction Work, which contractor(s) or construction manager(s) and applicable Initial Construction Contract has been approved by Lender as set forth in Section 3.1.
Sample 1Sample 2
Initial Contractor means the unincorporated joint venture established between
Sample 1
Initial Contractor means [the unincorporated joint venture established between] [insert name of contractor who is to carry out the Initial Construction Works];
Sample 1

Examples of Initial Contractor in a sentence

  • Accept (Initial) Reject (Initial) Contractor and State shall identify the contract manager who shall serve as the point of contact for the executed contract.

  • Accept (Initial) Reject (Initial) Contractor certifies it maintains a drug free work place environment to ensure worker safety and workplace integrity.

  • Accept (Initial) Reject (Initial) Contractor may be required to work with or in close proximity to other contractors or individuals that may be working on same or different projects.

  • Accept (Initial) Reject (Initial) Contractor may be required to work with or in close proximity to other contractors or individuals that may be working on the same or different projects.

  • Accept (Initial)Reject (Initial) Contractor may be required to work with or in close proximity to other contractors or individuals that may be working on the same or different projects.

  • Accept (Initial)Reject (Initial) Contractor certifies it maintains a drug free work place environment to ensure worker safety and workplace integrity.

  • Accept (Initial) Reject (Initial) Contractor certifies it maintains a drug free workplace environment to ensure worker safety and workplace integrity.

  • Any ambiguity or conflict in the contract discovered after its execution, not otherwise addressed herein, shall be resolved in accordance with the rules of contract interpretation as established in the State of Nebraska.NOTIFICATION Accept (Initial) Reject (Initial) Contractor and State shall identify the contract manager who shall serve as the point of contact for the executed contract.

  • COOPERATION WITH OTHER CONTRACTORS Accept (Initial) Reject (Initial) Contractor may be required to work with or in close proximity to other contractors or individuals that may be working on same or different projects.

  • The Contractor will be paid for the quantity of the work done at the rate in the Bills of Quantities for each item.If the final quantity of the work done differs from the quantity in the Bills of Quantities for the particular item by more than 25 percent and provided the change exceeds 1 percent of the Initial Contractor price, the Project Manager shall adjust the rate to allow for the change.


More Definitions of Initial Contractor

Initial Contractor means the unincorporated joint venture established between [insert name of contractor who is to carry out the Initial Construction Works];
Sample 1

Related to Initial Contractor

  • Residential contractor means a licensed contractor that holds an endorsement as a:

  • Original contractor means a person, including an owner-builder, that contracts with an owner to provide preconstruction service or construction work.

  • Initial Contracts means those Contracts conveyed to the Trust on the Closing Date.

  • O&M Contractor means the person, if any, with whom the Concessionaire has entered into an O&M Contract for discharging O&M obligations for and on behalf of the Concessionaire;

  • EPC Contractor means the contractor responsible for engineering, procurement and construction of the Facility, including Seller if acting as contractor, and including all subcontractors.

  • General Contractor means a person or entity duly licensed in the state of Florida with the requisite skills, experience and credit worthiness to successfully provide the units required in the Application, and which meets the criteria described in Rule 67-48.0072, F.A.C.

  • Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.

  • Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.

  • Sub-Contractor means the person named in the Contract for any part of the works or any person to whom any part of the contract has been sublet by the contractor with the consent in writing of the Engineer-in-charge and will include the legal representatives, successors and permitted assigns of such persons.

  • principal contractor means an employer appointed by the client to perform construction work;

  • Lead contractor means a person who has met the Board's requirements and has been issued a

  • Electrical contractor means an electrical contractor as defined in the Regulations;

  • Building Contractor means the building contractor or developer appointed or to be appointed by the Grant Recipient in respect of a Firm Scheme; Business Day means any day other than a Saturday, Sunday or a statutory Bank Holiday in England;

  • Home improvement contractor or "contractor" means a person who sells goods and services, or agrees to furnish or render services, to a retail buyer pursuant to a home improvement installment contract, or sells goods and services to a retail buyer pursuant to a home improvement charge agreement, but not in connection with construction of new homes.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Work means the work required to complete the Project.

  • Contract Work means everything required to be furnished and done by the Contractor by any one or more of the parts of the Contract referred to in Article 1, except Extra Work as hereinafter defined.

  • Replacement Contractor means any third party service provider appointed by the Authority to supply any services which are substantially similar to any of the Services and which the Authority receives in substitution for any of the Services following the expiry, termination or partial termination of the Contract.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Approved Contractor means an “Approved Contractor” specified in the Key Details.

  • Total Contract Price/Project Cost/TCO means the price payable to Service Provider over the entire period of Contract for the full and proper performance of its contractual obligations.

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Contractor means the individual or entity, that has entered into this contract with the Commonwealth.

  • Project Contract means any contract between the District or the Corporation and any contractor or vendor regarding the construction, production or other acquisition or installation of any part of an Acquisition Project.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • The Sub-Contractor means any person, firm or company (other than the Contractor) to whom any part of the work has been entrusted by the Contractor with the written consent of the Engineer-In-Charge and the legal representative successors and permitted assignee of such person, firm or company.