Need Date definition

Need Date means the date Buyer needs delivery of Goods which date is before, or after, the Delivery Date.
Sample 1Sample 2Sample 3
Need Date means the date LOCKHEED MARTIN needs delivery of Work which date is before, or after, the Delivery Date.
Sample 1Sample 2Sample 3
Need Date means the date Buyer needs delivery of goods which date is prior to or after the Contract Date.
Sample 1Sample 2

Examples of Need Date in a sentence

  • If Supplier agrees to the Need Date, the Need Date shall be considered the Delivery Date.

  • If Supplier agrees in writing to meet a Need Date, such Need Date shall be considered the Delivery Date.

  • If Supplier is unable to deliver Goods by the Need Date, Buyer may, without liability: (i) reduce or cancel its requirements for any part of the quantity of the Goods that cannot be delivered by the Need Date, (ii) reallocate to another Order, or reschedule, any portion of the Goods that cannot be delivered by the Need Date, or (iii) waive the Need Date and accept Goods on the Delivery Date.

  • If Supplier is unable to deliver Goods by the Need Date, Buyer may, without liability: (i) reduce or cancel its requirements for such Goods, (ii) reallocate to another Order, or reschedule, any such Goods, or (iii) waive the Need Date and accept such Goods on the Delivery Date.

  • If Buyer requests delivery of Goods on a date which do not allow sufficient Lead Time (a “Need Date”), Supplier shall use all commercially reasonable efforts to meet such Need Date.

  • The Contractor shall provide the updated accountability via IDE with the required items listed in line item format…Nomenclature, Part number, NSN, Location, Quantity, WBS, CLIN and Need Date.

  • Seller shall provide the updated physical inventory lists via IDE with the required items listed in line item format: at a minimum, Nomenclature, Part number, NSN, Location, Quantity, WBS, CLIN and Need Date.

  • Your prompt attention is required for formulation and approval of any necessary mitigation plans for the Network Upgrade(s) if the Need Date OR Estimated In-Service Date is not feasible.

  • SPP staff currently identifies an SPP Determined Need Date as part of the ITP process, which is published as part of the STEP and included in NTCs issued after projects have been approved by the Board of Directors.

  • Additionally, if it is anticipated that the completion of any Network Upgrade will be delayed past the Need Date OR Estimated In-Service Date, SPP requires a mitigation plan be filed within 60 days of the determination of expected delays.


More Definitions of Need Date

Need Date means the date Buyer needs delivery of Goods which date is before, or after, the Delivery Date. “Party” or “Parties” means Buyer and/or Supplier, individually or collectively, as the context requires. “Prime Contract” means the government or commercial sales contract between Buyer and Buyer’s Customer.
Sample 1
Need Date means the date identified by the Covered Individual or his/her physician as documented on the order.
Sample 1

Related to Need Date

  • Designated Date means September 30, 2006.

  • Appointed Date means the date declared by the Authority as the project commencement date with the consent of the contractor, as per the process prescribed in Article 3 and 8 of this Agreement;

  • Date The Effective Date (as defined in the Funding Agreement) Acknowledged and Agreed: THE PRINCIPAL LIFE INCOME FUNDINGS TRUST DESIGNATED IN THIS GUARANTEE By: U.S. Bank Trust National Association, not in its individual capacity, but solely in its capacity as trustee By: Bankers Trust Company, N.A., under Limited Power of Attorney, dated February 16, 2006 By: /s/ Dxxxx X. Xxxx Name: Dxxxx X. Xxxx Title: Vice President Date: The Effective Date (as defined in the Funding Agreement)

  • Drop Dead Date has the meaning set forth in Section 9.01(b)(i).

  • Service Commencement Date means the date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Tariff, Part II, section 15.3 or Tariff, Part III, section 29.1.

  • Contract Date means the date set for bid opening or, if this is a negotiated contract or a modification, the effective date of this contract or modification.

  • Qualification Date means the date as of which the Offering Statement was or will be qualified with the Commission pursuant to Regulation A, the Act and the Rules and Regulations; and

  • Presentation Date means a day which (subject to Condition 12 (Prescription)):

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Starting Date means the date referred to in Clause 3.3 hereof;

  • commencement day means the day on which the State Administrative Tribunal (Conferral of Jurisdiction) Amendment and Repeal Act 2004 Part 2 Division 29 comes into operation;