Partial Commercial Operation Date definition

Partial Commercial Operation Date means the date on which the conditions set forth in Section 3.3(b) have been satisfied with respect to a portion of the Facility, as set out in a written notice from Seller to Buyer.
Sample 1Sample 2Sample 3
Partial Commercial Operation Date means the date on which Partial Commercial Operation shall have occurred.
Sample 1
Partial Commercial Operation Date means the day following the date on which the Seller’s Interconnection Facilities are installed
Sample 1

Examples of Partial Commercial Operation Date in a sentence

  • Seller’s obligation to Deliver the Products and Buyer’s obligation to pay Seller for such Products from any Phase commences on the Partial Commercial Operation Date for that Phase; provided that Energy, Capacity and RECs generated by a Phase prior to the Partial Commercial Operation Date for that Phase shall not be deemed Products.

  • Seller shall maintain the Facility’s status as a QF or EWG at all times after the first Partial Commercial Operation Date and shall obtain and maintain any requisite authority to sell the output, including Capacity, of the Facility at market-based rates or an exemption from the requirement that it have such authority.

  • During the period prior to the Partial Commercial Operation Date for each Phase (each a “Test Period”), Seller shall sell and Deliver, and Buyer shall purchase and receive, Buyer’s Percentage Entitlement of any Energy and RECs produced by that Phase.

  • Before the Phase Two Partial Commercial Operation Date, Producer shall perform (or allow TU Electric, at TU Electric's option, to perform, at Producer's expense) the following tests ("Performance Tests") on Phase Two of the Renewable Resource Facility.

  • Seller shall cause the Project to achieve the Construction Start Date by the Guaranteed Construction Start Date, the Partial Commercial Energy Delivery Date by the Guaranteed Partial Commercial Operation Date, and the Full Commercial Energy Delivery Date by the Guaranteed Full Commercial Operation Date.

  • Buyer shall be entitled to draw upon the Post Effective Date Project Development Security and the Initial Energy Delivery Security posted by Seller for Daily Delay Damages related to the Guaranteed Construction Start Date, the Guaranteed Partial Commercial Operation Date, and the Guaranteed Full Commercial Operation Date, as applicable, up to the Maximum Delay Damages Amount.

  • Producer must pay the entire Interconnection Costs before the Phase One Partial Commercial Operation Date.

  • Services Term” is the period during which Buyer is obligated to purchase Products Delivered to Buyer by Seller (not including any Energy and RECs Delivered during the Test Period under Section 4.9), commencing on the first Partial Commercial Operation Date and, subject to Section 2.2(c), continuing for a period of fifteen (15) years from the Commercial Operation Date, unless this Agreement is earlier terminated in accordance with the provisions hereof.

  • The Renewable Resource Facility may not be connected to TU Electric's system before the Phase One Partial Commercial Operation Date, except to perform the Performance Tests outlined in Section 2.02(a) on Phase One of the Renewable Resource Facility and as approved by TU Electric in writing in advance.

  • The Renewable Resource Facility's "Partial Commercial Operation" begins at 12:01 a.m. on the Phase One Partial Commercial Operation Date and continues until the Commercial Operation Date or until this Agreement is terminated, whichever occurs first.


More Definitions of Partial Commercial Operation Date

Partial Commercial Operation Date means the date on which Seller has (a) notified Buyer that Partial Commercial Operation has occurred, and (b) provided to Buyer a certification of a Licensed Professional Engineer, substantially in the form attached hereto as Appendix VI-B, demonstrating satisfactory completion of the Commercial Operation Certification Procedure as provided in Appendix V hereto in respect of Partial Commercial Operation.
Sample 1
Partial Commercial Operation Date shall have the meaning set forth in Clause 14.1.2 of this Agreement;
Sample 1

Related to Partial Commercial Operation Date

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.

  • Commercial Operation means the condition of operation in which the complete equipment covered under the Contract is officially declared by the Owner to be available for continuous operation at different loads up to and including rated capacity. Such declaration by the Owner, however, shall not relieve or prejudice the Contractor of any of his obligations under the Contract.

  • Commence commercial operation means, with regard to a unit that serves a generator, to have begun to produce steam, gas, or other heated medium used to generate electricity for sale or use, including test generation subject to the following:

  • Date of Commercial Operation means the date on which the (nuclear or non-nuclear) power plant has successfully passed all performance and operational tests required by the end customer for commercial operation. In all other cases the warranty shall apply for twenty-four (24) months from delivery of the goods or performance of the services, or such longer period of time as customarily provided by Supplier, plus delays such as those due to non-conforming goods and services. The warranties shall apply to Buyer, its successors, assigns and the users of goods and services covered by this Order.

  • Scheduled Commercial Operation Date shall have the meaning ascribed to it in Clause 5.4.1;

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Commercial Operations Upon satisfaction of the following conditions, the Facility shall be considered to have achieved Commercial Operations on the Day specified in Seller's written notice described below: (i) the Acceptance Test has been passed, (ii) all generating units have passed Control System Acceptance Tests, (iii) the Transfer Date has occurred, (iv) Seller has (1) provided to Company the Required Models (as defined in Section 6(a) (Seller's Obligation to Provide Models) of Attachment B (Facility Owned by Seller)) in the form of Source Code, (2) placed the current version of the Source Code for the Required Models with the Source Code Escrow Agent as required in Section 6(b)(i)(A) (Establishment of Source Code Escrow) of Attachment B (Facility Owned by Seller), or (3) if Seller is unable to arrange for the placement of the appropriate Source Code into the Source Code Escrow account, placed the required funds with the Monetary Escrow Agent as required in Section 6(b)(ii)(A) (Establishment of Monetary Escrow) of Attachment B (Facility Owned by Seller), and (v) Seller provides Company with written notice that (aa) Seller is ready to declare the Commercial Operations Date and (bb) the Commercial Operations Date will occur within 24 hours (i.e., the next Day).

  • Guaranteed Commercial Operation Date has the meaning set forth in Section 3.9(c)(i).

  • Initial Operation means the first integral operation of the complete equipment covered under the Contract with the sub-system and supporting equipment in service or available for service.

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Billing Commencement Date means the earlier of:

  • Loan Commencement Date means, with respect to each Growth Capital Loan: (a) the first day of the first full calendar month following the Borrowing Date of such Loan if such Borrowing Date is not the first day of a month; or (b) the same day as the Borrowing Date if the Borrowing Date is the first day of a month.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Distribution Commencement Date means the Issue Date or such other date as may be specified as the Distribution Commencement Date on the face of such Perpetual Security;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Service Commencement Date means the date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Tariff, Part II, section 15.3 or Tariff, Part III, section 29.1.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Lease Commencement Date means the Closing Date. The “Lease Expiration Date” shall mean the later of (i) the date of the final payment in full of the French Advances and (ii) the Vehicle Lease Expiration Date for the last Lease Vehicle leased by the Lessee hereunder. The “Term” of this Agreement shall mean the period commencing on the Lease Commencement Date and ending on the Lease Expiration Date.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Normal operation means all periods of operation except start-up and shutdown operations and maintenance of equipment;

  • Services Commencement Date means the date delivery of the Services shall commence as specified in the Key Provisions. If no date is specified in the Key Provisions this date shall be the Commencement Date;

  • Payment Commencement Date means the date payments of amounts deferred begin pursuant to Article III, Section 6.