Prior Occupancy definition

Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.
Sample 1Sample 2Sample 3
Prior Occupancy means Owner's use of all or parts of the Project before Substantial Completion.
Sample 1Sample 2Sample 3
Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion.
Sample 1Sample 2Sample 3

Examples of Prior Occupancy in a sentence

  • Unless otherwise agreed in writing, Prior Occupancy shall not: be deemed an acceptance of any portion of the Work; accelerate the time for any payment to the CM/GC; prejudice any rights of Owner provided by any insurance, bond, guaranty, or the Contract Documents; relieve the CM/GC of the risk of loss or any of the obligations established by the Contract Documents; establish a date for termination or partial termination of the assessment of liquidated damages; or constitute a waiver of claims.


More Definitions of Prior Occupancy

Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Part 6.7A.
Sample 1Sample 2Sample 3
Prior Occupancy. Tenant shall not occupy any portion of the Leased Premises prior to Lease Commencement Date except with the express prior written consent of Landlord. If with Landlord's consent, Tenant occupies the Leased Premises prior to the Lease Commencement Date, Tenant shall pay Landlord Base Rent in the amounts specified in Paragraph 1.1 and Tenant's Pro Rata Share of Operating Costs, as defined in Paragraph 3.3, from the first day of such occupancy. These amounts will be payable on the first day of such occupancy and thereafter on the first day of every calendar month until the first day of the Lease Term. A prorated monthly installment shall be paid for the fraction of the month if Tenant's occupancy of the Leased Premises commences on any day other than the first day of the month. If Tenant shall occupy the Leased Premises prior to Lease Commencement Date, all covenants and conditions of this Lease shall be binding on Tenant commencing at such prior occupancy.
Sample 1
Prior Occupancy. Tenant shall not occupy the Leased Premises prior to Lease Commencement Date except with the express prior written consent of Landlord. If with Landlord's consent Tenant occupies the Leased Premises, Tenant shall pay Landlord for the period from the first day of such occupancy rent in the amount specified in Article 1.1 to be payable on the first day of such occupancy and thereafter on the first day of every calendar month until the first day of the Lease Term. A prorated monthly installment shall be paid for the fraction of the month if Tenant's occupancy of the Leased Premises commences on any day other than the first day of the month. If Tenant shall occupy the Leased Premises prior to Lease Commencement Date, all covenants and conditions of this Lease shall be binding on the parties commencing at such prior occupancy.
Sample 1
Prior Occupancy means Ecology or property owner use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08A.
Sample 1

Related to Prior Occupancy

  • Single Room Occupancy or “SRO” means housing consisting of single room dwelling units that is the primary residence of its occupant or occupants. An SRO does not include facilities for students.

  • Owner-occupied means property that is the principal

  • Occupancy means the use or intended use of a building or part thereof for the shelter or support of persons, animals or property.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Certificate of Occupancy means a certificate of occupancy, governmental sign-off or other document, permit or approval (whether conditional, unconditional, temporary or permanent) which must be obtained by Landlord from the appropriate governmental authority as a condition to the lawful initial occupancy by Tenant of the Expansion Space that is the subject of the Work.

  • Subleased Premises means all that portion of the Leased Premises referred to as airport lot as outlined on the site diagram attached as Schedule "A" to this Sublease; and

  • the Premises means the building or part of the building booked and referred to in the contract

  • Leased space means individual storage space at a self-service storage facility which is rented to an occupant pursuant to a rental agreement.

  • Leased Premises means the Leased Premises as defined in Paragraph 1.

  • Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;

  • Unoccupied means the dwelling is not being inhabited as a residence.

  • Tenant Delay means any actual delay that Landlord may encounter in the performance of Landlord’s obligations under this Lease by reason of (i) any intentional act, negligence or omission (where there is a duty to act) of any nature of Tenant or Tenant’s agents, employees, contractors, architects, space designers, subcontractors or invitees, including, without limitation, (1) delay from or by the New York City Department of Buildings or other like governmental agencies due to any Alteration or work requested by Tenant or special permits or licenses required by Tenant in connection therewith (except to the extent any such delay is caused by acts of Landlord or its agents), (2) delays due to changes in or additions to any work (including, but not limited to, Landlord’s Work) requested by Tenant after Landlord’s approval of Final Plans, (3) Tenant’s failure to timely submit information or to timely give authorizations or approvals required to be given by Tenant within the time periods required hereunder or in the Work Agreement or delays resulting from the fact that, under good construction practice, portions of Landlord’s Work or approved Additional Work must be scheduled after the completion of certain items of Tenant’s Installations (as defined in the Work Agreement), and/or (4) delays caused by a material breach of this Lease by Tenant or Persons Within Tenant’s Control, or the willful misconduct or negligence of Tenant or Persons Within Tenant’s Control, (ii) postponement of any item of Landlord’s Work at the request of Tenant, (iii) Tenant’s interference with the performance of Landlord’s Work in connection with Tenant’s entry into the Premises pursuant to the Work Agreement, (iv) Tenant’s request for materials or products in Landlord’s Work or Additional Work which must be specially fabricated to order or are not readily available for delivery, (v) Tenant’s requests for or the performance of Additional Work or Tenant’s failure to timely approve and/or pay the Excess Additional Work Cost (as defined in the Work Agreement) as set forth in Paragraph B of Article II of the Work Agreement, (vi) a delay set forth in clauses (w) through (z) in Paragraph B of Article I of the Work Agreement or set forth in the last sentence of Paragraph A of Article II of the Work Agreement. For the avoidance of doubt, the term “Tenant Delay” shall include any delay which is expressly stated in this Lease or in the Work Agreement to be a Tenant Delay. In order to claim that a Tenant Delay has occurred, Landlord shall promptly notify Tenant after Landlord has actual knowledge of a Tenant Delay and state in reasonable detail the basis of such Tenant Delay. Any such period of Tenant Delay shall not exceed the time period Landlord was actually delayed as a result of such Tenant Delay and any simultaneous Tenant Delays shall be deemed to run concurrently and not consecutively and shall not be “double” counted.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth).

  • residential premises means a house, building, structure, shelter, or mobile home, or portion thereof, used as a dwelling, home, residence, or living place by 1 or more human beings. “Residential premises” includes an apartment unit, a boardinghouse, a rooming house, a mobile home, a mobile home space, and a single or multiple family dwelling, but does not include a hotel, a motel, motor home, or other tourist accommodation, when used as a temporary accommodation for guests or tourists, or premises used as the principal place of residence of the owner and rented occasionally during temporary absences including vacation or sabbatical leave.