Renovation Commencement Date definition

Renovation Commencement Date means the date set out in the Addendum, if applicable, by which you must commence Renovation Work.
Sample 1Sample 2Sample 3
Renovation Commencement Date means the date set out in the Addendum, if applicable, by which you must commence Renovation Work. "Renovation Work" means the renovation and/or construction work, including purchasing and/or leasing and installation of all fixtures, equipment, furnishings, furniture, signs, computer terminals and related equipment, supplies and other items that would be required of a new System Hotel under the Manual, and any other equipment, furnishings and supplies that we may require for you to operate the Hotel as set out in any PIP applicable to the Hotel.
Sample 1Sample 2
Renovation Commencement Date with respect to any portion of the Premises vacated by Tenant to permit Landlord to perform the Renovation Improvements under the Improvement Agreement shall mean and date when all of the following have occurred: (a) Landlord has caused to be substantially completed on any given floor of the Premises all work to be performed by Landlord pursuant to the Improvement Agreement ("Landlord's Work"); (b) the City of Alameda has issued a temporary Certificate of Occupancy which permits Tenant to legally occupy that portion of the Premises and to commence the operation of its business therein; (c) possession of any portion of the Premises has been tendered by Landlord to Tenant; (d) all utility services are available for use by Tenant; and (e) there are no uncompleted items or defects in construction relating to the Renovation Improvements which would materially interfere with Tenant's ability to use the Premises for the uses permitted by the Lease.
Sample 1

Examples of Renovation Commencement Date in a sentence

  • You will begin the Renovation Work on or before the Renovation Commencement Date specified in the Rider and will continue the Renovation Work uninterrupted, except to the extent continuation is prevented Force Majeure, until it is completed.

  • You agree that the Renovation Commencement Date and Renovation Work Completion Date may be extended by written notice from us in our business judgment.

  • You agree that the Renovation Commencement Date and Renovation Work Completion Date may be extended by written notice from us in our discretion.

  • By taking possession of such portion of the Premises as of the Renovation Commencement Date, Tenant will accept such Premises as being in good and sanitary order, condition and repair and will accept that portion of the Premises in their condition existing as of the date of such entry, subject to (i) latent defects, and (ii) punch list items as identified during the inspection to be undertaken pursuant to the Improvement Agreement.

  • If the entry by Tenant or its Agents prior to the applicable Renovation Commencement Date causes a delay in completing the construction of the Renovation Improvements, then the Renovation Commencement Date shall be deemed to have occurred on the date the Renovation Improvements would have been completed had there been no such delay caused by Tenant or its Agents.

  • Landlord and Tenant agree to amend this Lease to reflect that commencing on the date on which Tenant has completely vacated any given floor or portion of floor of the Premises in accordance with the schedule set forth in the Improvement Agreement and continuing until the Renovation Commencement Date for such floor, such floor and its related Rentable Area shall be deleted from the Premises.

  • This standardapplies to category 3–1 motorcycles, category 3–2 motorcycles, category 3–3 motorcycles, and category 3–4 motorcycles manufactured on and after September 1, 2014.

  • Concurrent with the Renovation Commencement Date for any given floor in the Building, Landlord and Tenant shall further amend this Lease to reflect the addition of such Rentable Area to the Premises and such amendment shall provide that until two weeks after such Renovation Commencement Date for such floor, Tenant shall not be obligated to pay Monthly Base Rent, Operating Expenses and Property Taxes due under this Lease pertaining to that portion of the Premises.

  • In any case, Tenant shall repair any damage to the Renovation Improvements constructed by Landlord pursuant to Exhibit "B" resulting from the entry ----------- upon the Premises by Tenant prior to the Renovation Commencement Date or caused by the installation of Trade Fixtures and equipment by Tenant or Tenant's Agents.

  • Following Tenant's vacation of a portion of the Premises and prior to the Renovation Commencement Date, Landlord shall perform Renovation Improvements in accordance with the terms of the Improvement Agreement.

Related to Renovation Commencement Date

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Loan Commencement Date means, with respect to each Growth Capital Loan: (a) the first day of the first full calendar month following the Borrowing Date of such Loan if such Borrowing Date is not the first day of a month; or (b) the same day as the Borrowing Date if the Borrowing Date is the first day of a month.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Lease Commencement Date means the Closing Date. The “Lease Expiration Date” shall mean the later of (i) the date of the final payment in full of the French Advances and (ii) the Vehicle Lease Expiration Date for the last Lease Vehicle leased by the Lessee hereunder. The “Term” of this Agreement shall mean the period commencing on the Lease Commencement Date and ending on the Lease Expiration Date.

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Offering Commencement Date means the first day of each Offering Period.

  • Rent Commencement Date means [Insert date or description] or any later date calculated in accordance with paragraph 3.3 of Part 5 of the Schedule;

  • the commencement date means the date on which the Contract shall take effect, as notified by the Authority to the Contractor in a letter awarding the Contract.

  • Commencement Date means the date of this Agreement;

  • Term Commencement Date shall be the later of (i) November 1, 2006 or (ii) the date on which Landlord’s Work is Substantially Complete (or the date on which Landlord’s Work would have been Substantially Complete absent Tenant Delay or Force Majeure (as defined below)); provided, however, that if the Term Commencement Date is not the first day of a calendar month, then the first lease year shall be extended through the last day of the calendar month in which the first 12-month period expires, and Rent for the additional period at the end of the first lease year shall be payable at the rate for the 12th month of the Term. “Force Majeure” means accident; breakage; repair; governmental regulation, moratorium or other governmental action. The “Term Expiration Date” shall be the day immediately preceding the seventh (7th) anniversary of the Term Commencement Date, provided that if such preceding day is not the last day of a calendar month, then the Term Expiration Date shall be the last date of the calendar month in which such preceding day occurs. Landlord and Tenant shall each execute and deliver to the other written acknowledgment of the actual Term Commencement Date and the Term Expiration Date when such are established, and shall attach it to this Lease as Exhibit B. Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Service Commencement Date means the date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Tariff, Part II, section 15.3 or Tariff, Part III, section 29.1.

  • Policy Commencement Date means the date of commencement of the Policy as specified in the Schedule.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.

  • Billing Commencement Date means the earlier of:

  • Payment Commencement Date means the date payments of amounts deferred begin pursuant to Article III, Section 6.

  • Services Commencement Date means the date delivery of the Services shall commence as specified in the Key Provisions. If no date is specified in the Key Provisions this date shall be the Commencement Date;

  • Vesting Commencement Date means the Grant Date or such other date selected by the Committee as the date from which an Award begins to vest.

  • Distribution Commencement Date means the Issue Date or such other date as may be specified as the Distribution Commencement Date on the face of such Perpetual Security;

  • Pay Out Commencement Date means the date on which a Trust Pay Out Event is deemed to occur pursuant to Section 9.01 of the Agreement or a Series 2001-D Pay Out Event is deemed to occur pursuant to Section 7 hereof.

  • Employment Commencement Date means the date on which the Employee first performs an Hour of Service.

  • Recommencement Date As defined in Section 6(d) hereof.

  • Offer Commencement Date means the date on which Purchaser commences the Offer, within the meaning of Rule 14d-2 under the Exchange Act.

  • Annuity Commencement Date is the first day of the month an annuity begins under this contract. This date may not be later than the date a Participant's periodic benefits are required to commence under the Code.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Benefit Commencement Date means, for any Participant or beneficiary, the date as of which the first benefit payment, including a single sum, from the Participant’s Account is due, other than pursuant to a withdrawal under Article VIII.