Renovation Work Completion Date definition

Renovation Work Completion Date means any date set out in the Addendum by which you must complete Renovation Work.
Sample 1Sample 2Sample 3
Renovation Work Completion Date means the date set out in the Addendum, if applicable, by which you must complete Renovation Work.
Sample 1Sample 2Sample 3

Examples of Renovation Work Completion Date in a sentence

  • Notwithstanding any Force Majeure, or any other matter, the Renovation Work must be completed and the Hotel must be furnished, equipped, and comply with this Agreement no later than the Renovation Work Completion Date specified in the Rider.

  • You agree that the Renovation Commencement Date and Renovation Work Completion Date may be extended by written notice from us in our business judgment.

  • You agree that the Renovation Commencement Date and Renovation Work Completion Date may be extended by written notice from us in our discretion.

  • Renovation Work Completion Date: All Renovation Work must be completed in accordance with the dates set forth in the attached PIP.

  • Construction Work Completion Date or Renovation Work Completion Date specified in the Addendum.

  • Notwithstanding any Force Majeure, or any other matter, the Renovation Work must be completed and the Hotel must be furnished, equipped, and comply with this Agreement no later than the date specified in the Rider (the "Renovation Work Completion Date").

  • On verification of the event of Force Majeure, we will approve an extension of the Construction Commencement Date or Renovation Work Completion Date for up to eighteen (18) months.

Related to Renovation Work Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Construction Work means any work in connection with⎯

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Final Completion Date means the date on which Final Completion occurs.

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Tenant Improvements Defined in Exhibit B, if any.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Work crew means a program of partial confinement

  • Improvement completion assurance means a surety bond, letter of credit,

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and

  • Major renovation means the renovation of a building where:

  • Excavation work means the making of any man-made cavity, trench, pit or depression formed by cutting, digging or scooping;

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;