Round Completion Date definition

Round Completion Date means the latest date by which the Contractor shall achieve Round Completion.
Sample 1Sample 2Sample 3

Examples of Round Completion Date in a sentence

  • Short Notice restorations will be completed within five (5) Working Days of the Working Day the location was designated as a Short Notice restoration and submitted to the Contractor as such.D16.2 Short Notice restorations will be included in determining an extension of the Round Completion Date in accordance with D15.

  • Locations assigned as Emergency restorations may or may not be on the current Round list.D17.2 Emergency restorations will be included in determining an extension of the Round Completion Date in accordance with D15.

  • Each Round shall be completed by its Round Completion Date adjusted as required in accordance with D15.

  • D14.2 Should any additions in accordance with D13, to complete a Round be greater than the average daily rate multiplied by the Round Period, the Round Completion Date shall be extended based on eight (8) completed locations per day.

  • Therefore a Round Commencement Date may not immediately follow the Round Completion Date of the previous Round.

  • The Round Commencement Date will follow the specified Round Completion Date of a preceding Round adjusted in accordance with D15.

  • Sitting for long periods of time at a desk or on conference calls.

  • D15.2 Emergency restorations will be included in determining an extension of the Round Completion Date in accordance with D13.

  • D13.2 Should the actual amount of sod to be placed, including any additions in accordance with D12, to complete a Round be greater than the average daily rate multiplied by the Round Period, the Round Completion Date shall be extended based on one hundred fifty (150) sq.

  • D14.2 Short Notice restorations will be included in determining an extension of the Round Completion Date in accordance with D13.

Related to Round Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion Date means the date on which Final Completion occurs.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Start-up Period means up to 7 Academy Financial Years and covers the period up to and including the first Academy Financial Year in which all age groups are present at the Academy (that is, all the pupil cohorts relevant to the age range of the Academy will have some pupils present).

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.