Target Substantial Completion Dates definition

Target Substantial Completion Dates means collectively the Target Substantial Completion Date for Subproject 1 and Target Substantial Completion Date for Subproject 2.
Sample 1Sample 2Sample 3

Examples of Target Substantial Completion Dates in a sentence

  • Contractor shall be entitled to an extension to the applicable Target Substantial Completion Dates and/or Guaranteed Substantial Completion Dates for delay or prevention that meets the requirements of this Section 6.8A, if and to the extent such delay or prevention causes a delay in the critical path of the Work.

  • Owner’s review and comments regarding the Recovery Schedule shall not relieve Contractor of any obligations for performance of the Work, change the Target Substantial Completion Dates or Guaranteed Substantial Completion Dates or be construed to establish the reasonableness of the Recovery Schedule.

  • Listed in Attachment E are Target Substantial Completion Dates for each Subproject.

  • Even if the Work is otherwise in compliance with the CPM Schedule, Owner may, at any time, direct Contractor in writing to advance one or all of the Target Substantial Completion Dates and Guaranteed Substantial Completion Dates; provided, however, such directive shall be reasonable and Contractor shall have agreed in writing that such acceleration is commercially and technically feasible.

  • The Target Substantial Completion Dates shall only be adjusted by Change Order as provided under this Agreement.

  • Consideration The Consideration is HK$43,000,000 which shall be payable in cash on the Completion Date.

  • Contractor shall be entitled to an adjustment to the Contract Price for reasonable, additional costs incurred by Contractor for delay or in mitigation or avoidance of a delay which would otherwise meet such requirements of this Section 6.9. For the avoidance of doubt, this Section 6.9 shall govern the determination of any right of Contractor to an adjustment to the Target Substantial Completion Date(s) and Guaranteed Substantial Completion Date(s) for delay unless such delay is caused by Force Majeure.

  • Listed in Attachment 5 are the Target Substantial Completion Dates.

  • Notwithstanding the foregoing, any adjustment to the Target Substantial Completion Date(s) shall extend the Guaranteed Substantial Completion Dates in the same amounts so that the Guaranteed Substantial Completion Date for a Subproject is always fifty nine (59) Days after the Target Substantial Completion Date for such Subproject, regardless of whether the delay impacts only the critical path of the Work to achieve the Target Substantial Completion Date and not the Guaranteed Substantial Completion Date.

  • Even if the Work is otherwise in compliance with the CPM Schedule, Owner may, at any time, direct Contractor in writing to advance one or both of the Target Substantial Completion Dates and the Guaranteed Substantial Completion Dates for one or both of Project 1 and Project 2; provided, however, such directive shall be reasonable and Contractor shall have agreed in writing that such acceleration is commercially and technically feasible.

Related to Target Substantial Completion Dates

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Project Milestone means the project milestone set forth in Schedule-J;