Target Substantial Completion Date for Subproject 2 means the date specified in Attachment E, which represents the target date for achieving Substantial Completion for Subproject 2.
Substantial Completion Date means the date on which Substantial Completion occurs.
Project Completion Date means the date on which the Completion Certificate is issued;
Target Completion Date has the meaning given such term in Section 3.3(b).
Final Completion Date means the date on which Final Completion occurs.
Subproject means a development activity proposed by a Beneficiary under Part A.2 (d) of the Project and financed or to be financed through a Subproject Grant (as hereinafter defined) made out of the proceeds of the Development Credit;
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Subprojects means more than one such Subproject.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.
Final Completion Certificate has the meaning set forth in Section 11.6.
Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.
Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Commissioning test means tests applied to the Generating Facility, after completion of the construction of the Generating Facility, in order to verify that the Generating Facility may be released for Operation.
Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.
Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
Project Milestone means the project milestone set forth in Schedule-J;
Project Milestones means the project milestones set forth in Schedule-G;
Development Milestone Event shall have the meaning set forth in Section 9.2(a).
Subproject Agreement means any of the agreements referred to in Section 3.07 of this Agreement; and