Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Environmental Damages means all claims, judgments, damages, losses, penalties, fines, liabilities, encumbrances, liens, costs and expenses of investigation and defense of any claim, including, without limitation, attorney’s fees, that are incurred at any time as a result of the existence of Environmental Conditions upon, about or beneath the Project Site or migrating or threatening to migrate to or from the Site, and including, without limitation:
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Property damage means physical injury to, destruction of, or loss of use of tangible property.
Special Damages shall have the meaning as set forth in Section 5.07.
Direct Damage has the meaning given to it in clause 26.2;
Seller Damages shall have the meaning given to such term in Section 14.3.
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Actual Damages has the meaning set forth in Section 12.4(C).
Severe property damage means substantial physical damage to property, damage to the treatment facilities which would cause them to become inoperable, or substantial and permanent loss of natural resources which can reasonably be expected to occur in the absence of a bypass. Severe property damage does not mean economic loss caused by delays in production.
Resale Damages means, with respect to any Rejected Purchase, an amount equal to (a) the positive net amount, if any, by which the applicable Price that would have been paid pursuant to Section 4.4 hereof for such Rejected Purchase, had it been accepted, exceeds the Resale Price multiplied by the quantity of that Rejected Purchase, plus (b) any applicable penalties assessed by ISO-NE or any other Person against Seller as a result of Buyer’s failure to accept such Products. Seller shall provide a written statement explaining in reasonable detail the calculation of any Resale Damages.
Consequential Loss means loss of profits, anticipated loss of profit or revenue, loss of production, loss of business opportunity, loss of or damage to goodwill or reputation, loss of use or any other similar loss, but excludes:
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Environmental Damage means any injury or damage to persons, living organisms or property (including offence to man’s senses) or any pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Product Liability means any liability, claim or expense, including but not limited to attorneys’ fees and medical expenses, arising in whole or in part out of a breach of any express or implied product warranty by the Company, strict liability in tort, negligent manufacture of product, negligent provision of services, product recall, or any other allegation of liability arising from the design, testing, manufacture, packaging, labeling (including instructions for use), or sale of products.
Rejection Damages Claim means any Claim on account of the rejection of an Executory Contract or Unexpired Lease pursuant to section 365 of the Bankruptcy Code.
Cover Damages means, with respect to any Delivery Shortfall, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 and the Cover Sheet, multiplied by the quantity of that Delivery Shortfall, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Noneconomic damages ’ means damages for phys-
Products Liability means:Your legal liability in respect of Personal Injury and/or Property Damage caused by or arising out of any Products or the reliance upon a representation or warranty made at any time with respect to such products; but only where such Personal Injury and/or Property Damage occurs away from premises owned or leased by or rented to You and after physical possession of such products has been relinquished to others.
Breach of Contract means the failure of a Party to perform any of its obligations in accordance with this Contract, in whole or in part or in a timely or satisfactory manner. The institution of proceedings under any bankruptcy, insolvency, reorganization or similar law, by or against Contractor, or the appointment of a receiver or similar officer for Contractor or any of its property, which is not vacated or fully stayed within 30 days after the institution of such proceeding, shall also constitute a breach. If Contractor is debarred or suspended under §24-109-105, C.R.S. at any time during the term of this Contract, then such debarment or suspension shall constitute a breach.
Breach of system security means unauthorized acquisition of computerized data that compromises the security, confidentiality, or integrity of sensitive personal information maintained by a person, including data that is encrypted if the person accessing the data has the key required to decrypt the data. Good faith acquisition of sensitive personal information by an employee or agent of the person for the purposes of the person is not a breach of system security unless the person uses or discloses the sensitive personal information in an unauthorized manner. Business and Commerce Code 521.053(a)
Maximum Liability has the meaning assigned to such term in Section 10.10.