XXXX Contract Capacity definition

XXXX Contract Capacity. The storage capacity, in MWh, of the XXXX, or ___ MWh.
Sample 1Sample 2Sample 3
XXXX Contract Capacity shall have the meaning set forth in Exhibit L.
Sample 1Sample 2Sample 3
XXXX Contract Capacity means the net nameplate capacity of the XXXX equal to fifty- nine (59) MW AC as of the Effective Date and reduced during the Delivery Term as set forth in Appendix B-1, or such other applicable amounts determined in accordance with Appendix A-2.
Sample 1Sample 2

Examples of XXXX Contract Capacity in a sentence

  • For the purposes of evaluating the XXXX Capacity Test, the "XXXX Capacity Ratio" shall be equal to the number, expressed as a percentage, equal to the total MWh delivered to the Point of Interconnection during the XXXX Capacity Test, divided by the XXXX Contract Capacity.

  • JH COMPLETION DATE: 06/28/96 WORK ORDER COMPLETED BY: BB ATTACHMENT W XXXX TESTS Prior to achieving Commercial Operations and in each XXXX Measurement Period, unless waived by Company, Seller shall demonstrate that the XXXX satisfies the following: Maintains output provided by the Company through a control setpoint, as measured at the Point of Interconnection, and is able to continuously dispatch the full XXXX Contract Capacity ("XXXX Capacity Test").

  • Date/Time Start Date/Time End Total MWh delivered to the POI (A) XXXX Contract Capacity (MWh) (B) XXXX Capacity Ratio 100% x (A ÷ B) Enter the applicable information from which the IPP is using to demonstrate satisfaction of the RTE Performance Metric during the reporting period.

  • For storage used primarily for energy shifting, the XXXX shall be designed for an average annual use of 365 cycle(s) (a cycle is a discharge equal to the portion of the XXXX Contract Capacity allocated for energy shifting, and sufficient charging to return the XXXX to 100% State of Charge) For contingency storage, the XXXX storage technology shall be procured based on required charging/discharging duty for the provision of disturbance frequency response.

  • For storage used primarily for energy shifting, the XXXX shall be designed for an average annual use of 365 cycle(s) (a cycle is a discharge equal to the portion of the XXXX Contract Capacity allocated for energy shifting, and sufficient charging to return the XXXX to 100% State of Charge).

  • For storage used primarily for energy shifting, the XXXX shall be designed for an average annual use of 365 cycle(s) (a cycle is a discharge equal to the XXXX Contract Capacity, and sufficient charging to return the XXXX to 100% State of Charge) For contingency storage, the XXXX storage technology shall be procured based on required charging/discharging duty for the provision of disturbance frequency response.

  • Buyer shall have the option to request at any time prior to July 1 of Contract Year twelve (12) an augmentation of the XXXX during Contract Year fourteen (14), in order for the XXXX to meet the XXXX Contract Capacity from Contract Year fifteen (15) or other such later time until the end of the Delivery Term (the “XXXX Augmentation”).

  • Any XXXX Capacity Test, other than where the XXXX Contract Capacity is demonstrated by reference to operational data reflecting the net output of the XXXX as provided below, shall be performed at a time reasonably requested by the Company in its sole discretion.

  • JH COMPLETION DATE: 06/28/96 WORK ORDER COMPLETED BY: BB ATTACHMENT W XXXX CAPACITY TEST Prior to achieving Commercial Operations and in each XXXX Measurement Period, unless waived by Company, Seller shall demonstrate that the XXXX satisfies the following ("XXXX Capacity Test"): Maintains output provided by the Company through a control setpoint, as measured at the Point of Interconnection, and is able to continuously dispatch the full XXXX Contract Capacity.

  • Article 26(4) of the ECT provides that an Investor may consent to arbitration and “choose[ ] to submit [a] dispute for resolution” through, inter alia, “an arbitral proceeding under the [SCC].” That Investor’s consent and a State’s unconditional consent to arbitrate under Article 26(3) together constitute the disputing parties’ arbitration agreement, which, by extension, incorporates the underlying rules of the arbitral procedure selected by an Investor under Article 26(4).

Related to XXXX Contract Capacity

  • Contract Capacity has the meaning set forth in Section 3.1(f).

  • Project Capacity means the AC capacity of the project at the generating terminal(s) and to be contracted with MSEDCL for supply from the Solar Power Project.

  • Potential electrical output capacity means, with regard to a unit, 33 per- cent of the maximum design heat input of the unit.

  • System Capacity means the operational capacity of the System at any applicable point in time.

  • Storage Capacity means any combination of space, injectability and deliverability.

  • Excess capacity means volume or capacity in a duct, conduit, or support structure other than a utility pole or anchor which can be used, pursuant to the orders and regulations of the Commission, for a pole attachment.

  • Idle capacity means the unused capacity of partially used facilities. It is the difference between: (a) that which a facility could achieve under 100 percent operating time on a one-shift basis less operating interruptions resulting from time lost for repairs, setups, unsatisfactory materials, and other normal delays; and (b) the extent to which the facility was actually used to meet demands during the accounting period. A multi-shift basis should be used if it can be shown that this amount of usage would normally be expected for the type of facility involved.

  • Contracted Capacity means the capacity (in MW AC) contracted with MSEDCL for supply by the successful bidder at the Delivery Point from the Solar Power Project.

  • Nameplate Capacity means the maximum electrical generating output (in MWe) that a generator can sustain over a specified period of time when not restricted by seasonal or other deratings as measured in accordance with the United States Department of Energy standards.

  • Design capacity means the volume of a containment feature at a discharging facility that accommodates all permitted flows and meets all Aquifer Protection Permit conditions, including allowances for appropriate peaking and safety factors to ensure sustained, reliable operation.

  • Licensed capacity means the number of children the Department has determined the day care home can care for at any one time in addition to any children living in the home who are under the age of 12 years. Children age 12 and over on the premises are not considered in determining licensed capacity.

  • New Capacity means a new Generator, a substantial addition to the capacity of an existing Generator, or the reactivation of all or a portion of a Generator that has been out of service for five years or more that commences commercial service after the effective date of this definition. For purposes of Section 23.4.5 of this Attachment H, “Offer Floor” for a Mitigated Capacity Zone Installed Capacity Supplier that is not a Special Case Resource shall mean the lesser of (i) a numerical value equal to 75% of the Mitigation Net CONE translated into a seasonally adjusted monthly UCAP value (“Mitigation Net CONE Offer Floor”), or (ii) the numerical value that is the first year value of the Unit Net CONE determined as specified in Section 23.4.5.7, translated into a seasonally adjusted monthly UCAP value using an appropriate class outage rate, (“Unit Net CONE Offer Floor”). The Offer Floor for a Mitigated Capacity Zone Installed Capacity Supplier that is a Special Case Resource shall mean a numerical value determined as specified in Section 23.4.5.7.5. The Offer Floor for Additional CRIS MW shall mean a numerical value determined as specified in Section 23.4.5.7.6. For the purposes of Section 23.4.5 of this Attachment H, “Non-Qualifying Entry Sponsors” shall mean a Transmission Owner, Public Power Entity, or any other entity with a Transmission District in the NYCA, or an agency or instrumentality of New York State or a political subdivision thereof.

  • Committed Capacity means that portion of the Capacity that is required to meet the Capacity Entitlements of Access Holders;

  • Reserved Capacity means the maximum amount of capacity and energy that the Transmission Provider agrees to transmit for the Transmission Customer over the Transmission Provider’s Transmission System between the Point(s) of Receipt and the Point(s) of Delivery under Tariff, Part II. Reserved Capacity shall be expressed in terms of whole megawatts on a sixty (60) minute interval (commencing on the clock hour) basis.

  • Interruptible Capacity means capacity that may be interrupted by the Operator at any time in order to fulfil shippers’ nominations under a firm capacity reservation.

  • Unforced Capacity shall have the meaning specified in the Reliability Assurance Agreement.

  • Generation Capacity Resource shall have the meaning specified in the Reliability Assurance Agreement.

  • Base Capacity Resource means a Capacity Resource as described in Tariff, Attachment DD, section 5.5A(b).

  • Installed Capacity or 'IC’ means the summation of the name plate capacities of all the units of the generating station or the capacity of the generating station (reckoned at the generator terminals), approved by the Commission from time to time;

  • Maximum Capacity or ‘Pmax’ means the maximum continuous active power which a power-generating module can produce, less any demand associated solely with facilitating the operation of that power-generating module and not fed into the network as specified in the connection agreement or as agreed between the relevant system operator and the power-generating facility owner;

  • Final RTO Unforced Capacity Obligation means the capacity obligation for the PJM Region, determined in accordance with RAA, Schedule 8.

  • Bid Capacity meanss capacity offered by the bidder in his Bid under invitation.

  • Rated Capacity means the Average Daily Flow for which the Works are approved to handle;

  • Base Capacity Resource Price Decrement means, for the 2018/2019 and 2019/2020 Delivery Years, a difference between the clearing price for Base Capacity Resources and the clearing price for Capacity Performance Resources, representing the cost to procure additional Capacity Performance Resources out of merit order when the Base Capacity Resource Constraint is binding.

  • Available Capacity means the capacity from the Project, expressed in whole megawatts, that is available to generate Product. [For As-Available Product facilities only]

  • Technical Capacity means the maximum firm capacity that the transmission system operator can offer to the network users, taking account of system integrity and the operational requirements of the transmission network;