Use of Attachment Facilities by Third Parties Purpose of Attachment Facilities. Except as may be required by Applicable Laws and Regulations, or as otherwise agreed to among the Parties, the Attachment Facilities shall be constructed for the sole purpose of interconnecting the Large Generating Facility to the New York State Transmission System and shall be used for no other purpose.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
No Dedication of Facilities Any undertaking by one Party to the other Party under any provision of this Agreement shall not constitute the dedication of the system or any portion thereof by the Party to the public or to the other Party, and it is understood and agreed that any such undertaking under any provision of this Agreement by a Party shall cease upon the termination of its obligations hereunder.
Use of Interconnection Facilities by Third Parties 6551 Error! Hyperlink reference not valid.9.9.1 Purpose of Interconnection Facilities. 6551
Right to Refuse Dangerous Work An employee shall have the right to refuse to work in dangerous situations.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Use of Basement and Service Areas The basement(s) and service areas, if any, as located within the
Use of Facilities and Services Subject to the rules of the University and the terms of this Agreement, the UFF shall have the right to use University facilities for meetings and all other services on the same basis as they are generally available to other university-related organizations which are defined as follows: University-Related Groups and Organizations. These groups and organizations may or may not receive budgetary support. Examples of such groups include student organizations, honor societies, fraternities, sororities, alumni associations, faculty committees, University Support Personnel Systems council, direct support organizations, the United Faculty of Florida, etc.
Use of Facilities 34.1. In situations where the CLEC has the use of the facilities (i.e., local loop) to a specific customer premise, either through resale of local service or the lease of the local loop as an Unbundled Network Element, and Sprint receives a good faith request for service from a customer at the same premise or from another carrier with the appropriate customer authorization, the procedures below will apply.
34.1.1. Sprint will process such orders and provision services consistent with the terms contained in Section 82, of this Agreement.
34.1.2. Where CLEC is using a single facility to provide service to multiple end user customers, Sprint will not disconnect that facility as a result of the following procedures.
34.1.3. Sprint will follow methods prescribed by the FCC and any applicable state regulation for carrier change verification.
34.1.4. Customer with Existing Service Changing Local Service Provider
34.1.4.1. In situations where a CLEC submits an order for an end user customer that is changing local service providers for existing service, and is not adding service (i.e., an additional line), Sprint will process the service request without delay, and provide the losing local service provider a customer loss notification consistent with industry standards.
34.1.5. Customer with Existing Service Adding New Service
34.1.5.1. In situations where an order is submitted for an end user customer adding service to existing service (i.e., an additional line), the order should be marked as an additional line and CLEC’s facilities will not be affected.
34.1.6. Customer Requesting New Service where Previous Customer has Abandoned Service
34.1.6.1. In the case where an end user customer vacates premises without notifying the local service provider and a new end user customer moves into the vacated premises and orders new service from a local service provider neither Sprint nor the previous local service provider are aware that the original end user customer has abandoned the service in place.
34.1.6.2. When a carrier requests service at a location and marks the order as abandoned and CLEC is the previous local service provider, Sprint shall notify CLEC via fax that it has had a request for service at the premise location that is currently being served by CLEC;
34.1.6.3. If available to Sprint, Sprint shall include the name and address of the party receiving service at such locations, but at a minimum shall provide local service address location information;
34.1.7. If CLEC does not respond within twenty-four (24) hours after receiving Sprint’s notification or if CLEC responds relinquishing the facilities, Sprint shall be free to use the facilities in question and Sprint shall issue a disconnect order with respect to the CLEC service at that location. If CLEC responds stating that the service is working and should not be disconnected, Sprint will notify the carrier ordering service and request verification of the address and location or the submission of an order for an additional line.
