Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
REFERENCED CONTRACT PROVISIONS 2 Term: March 10, 20109 through June 30, 20110 3 “Period One” means the period from March 10, 2009 through June 30, 2009 4 “Period Two” means the period from July 1, 2009 through June 30, 2010 5 Maximum Obligation: $88,080 6 Period One Maximum Obligation: $ 44,040 7 Period Two Maximum Obligation: 8 TOTAL CONTRACT MAXIMUM OBLIGATION: $132,120 9 Basis for Reimbursement: Fee for Service 10 11 Payment Method: Fee for Service 12 Notices to COUNTY and CONTRACTOR: 14 COUNTY: County of Orange Health Care Agency 15 Contract Development and Management 16 000 Xxxx 0xx Xxxxxx, Xxxxx 000 00 Xxxxx Xxx, XX 00000-0000 18 CONTRACTOR: National Alliance on Mental Illness 19 dba NAMI Orange County 20 0000 X. 00xx Xxxxxx 00 Xxxxx Xxx, XX 00000 22 Coverage Minimum Limits 24 Workers' Compensation Statutory 25 Employer's Liability $1,000,000 26 Sexual Misconduct Insurance $1,000,000 Comprehensive General Liability Insurancewith $1,000,000 combined single limit 27 Comprehensive broad form Property damage and per occurrence including coverage 28 contractual liability $2,000,000 aggregate 29 Automobile Liability Insurance ), $1,000,000 combined single limit Workers' Compensation Statutory 30 coveringfor owned, non-owned, and hired ) vehicles) per occurrence 31 Employer's Liability Insurance $1,000,000 per occurrence Professional Liability Insurance $1,000,000 per claims made or 34 Sexual Misconduct $1,000,000 per occurrence 35 per occurrence 36
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Required Contract Provisions Private service provider contracts paid in whole or part with grant funds shall include the following provisions in the contract between the Grantee and the service provider:
Servicing Agreement General Summary The Sellers and the Purchasers intend this Agreement to amend and restate that certain “Servicing Agreement,” dated March 23, 2021, for purposes of the Purchase Agreement and wish to set forth herein the terms upon which each Purchaser will, to the fullest extent permitted by applicable Law and the applicable Corporate Trust Contract, and subject to the applicable provisions of this Agreement, assume the responsibility (as agent of the applicable Seller) to supervise, manage, administer and otherwise discharge the duties of the applicable Seller in a Corporate Trust Capacity under (a) any Restricted Appointment and (b) any Excluded Appointment (collectively, the “Serviced Appointments”), and the Purchasers will discharge and perform when due, and indemnify the Sellers for, the Assumed Servicing Liabilities.
190 Contract Complete This contract is the final expression of the Parties' agreement. There are no understandings, agreements, or representations, expressed or implied, which are not specified in this contract.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Performance and Compliance with Contracts and Credit and Collection Policy The Seller shall (and shall cause the Servicer to), at its expense, timely and fully perform and comply with all material provisions, covenants and other promises required to be observed by it under the Contracts related to the Receivables, and timely and fully comply in all material respects with the applicable Credit and Collection Policies with regard to each Receivable and the related Contract.
Prior Contracts This Contract supersedes and terminates, as of the date hereof, all prior contracts between the Fund and the Custodian relating to the custody of the Fund's assets.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
