Recovery of Sums Due Wherever any sum of money is recoverable from or payable by the Contractor, the Authority may deduct that sum from any sum due, or which at any later time may become due to the Contractor under the Contract or under any other agreement with the Authority.
C3 Recovery of Sums Due C3.1 Wherever under the Contract any sum of money is recoverable from or payable by the Contractor to the Authority (including any sum which the Contractor is liable to pay to the Authority in respect of any breach of the Contract), the Authority may unilaterally deduct that sum from any sum then due, or which at any later time may become due to the Contractor from the Authority under the Contract or under any other agreement or contract with the Authority or the Crown.
Recovery of Funds The right of the RECIPIENT to retain monies received as reimbursement payments is contingent upon satisfactory performance of this Agreement and completion of the work described in the Scope of Work. All payments to the RECIPIENT are subject to approval and audit by ECOLOGY, and any unauthorized expenditure(s) or unallowable cost charged to this Agreement shall be refunded to ECOLOGY by the RECIPIENT. RECIPIENT shall refund to ECOLOGY the full amount of any erroneous payment or overpayment under this Agreement. RECIPIENT shall refund by check payable to ECOLOGY the amount of any such reduction of payments or repayments within thirty (30) days of a written notice. Interest will accrue at the rate of twelve percent (12%) per year from the time ECOLOGY demands repayment of funds. Any property acquired under this Agreement, at the option of ECOLOGY, may become ECOLOGY's property and the RECIPIENT's liability to repay monies will be reduced by an amount reflecting the fair value of such property.
Recovery of Overpayments On occasion a payment will be made to You when You are not covered, for a service that is not Covered, or which is more than is proper. When this happens We will explain the problem to You and You must return the amount of the overpayment to Us within 60 days after receiving notification from Us. However, We shall not initiate overpayment recovery efforts more than 24 months after the original payment was made unless We have a reasonable belief of fraud or other intentional misconduct.
Recovery of Schedule Delays If the Design Professional determines that the Project is one week or more behind schedule, per the approved Overall Project Schedule, the Design Professional shall so notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Recovery of Costs If any legal action or other proceeding is brought for the enforcement of this Agreement, or because of an alleged dispute, breach, default or misrepresentation in connection with any of the provisions of this Agreement, the successful or prevailing party shall be entitled to recover reasonable attorneys’ fees and other costs incurred in that action or proceeding (and any additional proceeding for the enforcement of a judgment) in addition to any other relief to which it or they may be entitled.
TIPS Administration Fees The collection of administrative fees by TIPS, a government entity, for performance of these procurement services is required pursuant to Texas Government Code Section 791.011 et. seq. The administration fee (“TIPS Administration Fee”) is the amount legally owed by Vendor to TIPS for TIPS Sales made by Vendor. The TIPS Administration Fee amount is typically a set percentage of the amount paid by the TIPS Member for each TIPS Sale, less shipping cost, bond cost, and taxes if applicable and identifiable, which is legally due to TIPS, but the exact TIPS Administration Fee for this Contract is published in the corresponding solicitation and is incorporated herein by reference. TIPS Administration Fees are due to TIPS immediately upon Vendor’s receipt of payment, including partial payment, for a TIPS Sale. The TIPS Administration Fee is assessed on the amount paid by the TIPS Member, not on the Vendor’s cost or on the amount for which the Vendor sold the item to a dealer or Authorized Reseller. Upon receipt of payment for a TIPS Sale, including partial payment (which renders TIPS Administration Fees immediately due), Vendor shall issue to TIPS the corresponding TIPS Administration Fee payment as soon as possible but not later than thirty-one calendar days following Vendor’s receipt of payment. Vendor shall pay TIPS via check unless otherwise agreed to by the Parties in writing. Vendor shall include clear documentation with the issued payment dictating to which sale(s) the amount should be applied. Vendor may create a payment report within their TIPS Vendor Portal which is the preferred documentation dictating to which TIPS Sale(s) the amount should be applied. Failure to pay all TIPS Administration Fees pursuant to this provision may result in immediate cancellation of Vendor’s TIPS Contract(s) for cause at TIPS’ sole discretion as well as the initiation of collection and legal actions by TIPS against Vendor to the extent permitted by law. Any overpayment of participation fees to TIPS by Vendor will be refunded to the Vendor within ninety (90) days of receipt of notification if TIPS receives written notification of the overpayment not later than the expiration of six (6) months from the date of overpayment and TIPS determines that the amount was not legally due to TIPS pursuant to this agreement and applicable law. Any notification of overpayment received by TIPS after the expiration of six (6) months from the date that TIPS received the payment will render the overpayment non-refundable. Region 8 ESC and TIPS reserve the right to extend the six (6) month deadline if approved by the Region 8 ESC Board of Directors. TIPS reserves all rights under the law to collect TIPS Administration Fees due to TIPS pursuant to this Agreement.
Settlement and Recovery of Funding for Prior Years (a) The HSP acknowledges that settlement and recovery of Funding can occur up to 7 years after the provision of Funding.
Collection of Fees The Operating Committee shall establish a system for the collection of fees authorized under this Article XI. The Operating Committee may include such collection responsibility as a function of the Plan Processor or another administrator. Alternatively, the Operating Committee may use the facilities of a clearing agency registered under Section 17A of the Exchange Act to provide for the collection of such fees. Participants shall require each Industry Member to pay all applicable fees authorized under this Article XI within thirty (30) days after receipt of an invoice or other notice indicating payment is due (unless a longer payment period is otherwise indicated). If an Industry Member fails to pay any such fee when due (as determined in accordance with the preceding sentence), such Industry Member shall pay interest on the outstanding balance from such due date until such fee is paid at a per annum rate equal to the lesser of: (a) the Prime Rate plus 300 basis points; or (b) the maximum rate permitted by applicable law. Each Participant shall pay all applicable fees authorized under this Article XI as required by Section 3.7(b).
Delivery of Policies; Insurance Certificates Prior to commencing the Work, the Contractor shall deliver to NYSERDA certificates of insurance issued by the respective insurers, indicating the Agreement number thereon, evidencing the insurance required by Article XI hereof. In the event any policy furnished or carried pursuant to this Article will expire on a date prior to acceptance of the Work by NYSERDA pursuant to the section hereof entitled Acceptance of Work, the Contractor, not less than 15 days prior to such expiration date, shall deliver to NYSERDA certificates of insurance evidencing the renewal of such policies, and the Contractor shall promptly pay all premiums thereon due. In the event of threatened legal action, claims, encumbrances, or liabilities that may affect NYSERDA hereunder, or if deemed necessary by NYSERDA due to events rendering a review necessary, upon request the Contractor shall deliver to NYSERDA a certified copy of each policy.
